Loading...
429 NE 99 St (13)APPLICATION FOR BUILDING PERMIT Application is hereby made for the approval of the detailed statement of the plans and specifications herewith submitted for the build - ing or other structure herein described. This application is made in compliance and conformity with the Building Ordinance of Miami Shores Village, Florida, and all provisions of the Laws of the State of Florida, all ordinances of Miami Shores Village and all rules and regulations of the iuilding Division of Miami Shores Village shall be complied with, whether herein specified or not. A copy of approved plans and specifications must be kept at building during progress of the work. Date..._12✓..21✓..28 .._._...._._......__...._.... , 19.._._ Owner's Name and Address, Holland 429. .Ne--- Ea -_99- St, — No Street_... Registered Architect and /or Engineer Name and address of licensed contr actor.. F. an.. Ameriesn-. btterminalting.- iCo.- ...._..27. . .a.W....6. ..,...Miami.._._..__ Location and legal description of lot to be built on: Lot Block Subdivision Street and Number where work is to be done 429...N....E.... State work to be done and purpose of building (by floors) Residence Tent Fumigation and for no other purpose. New Building Remodeling Addition Repairs No. of Stories To be constructed of Kind of foundation Roof Covering Estimated Total cost of improvements $ Amount of Permit $..5..OD Zone cubage required plan Cubage Distance to next nearest building...10...ft. Size of Building Lot MSaxirnum live load to be borne by each floor I hereby submit all the plans and specifications for said building. All notices with reference to the building and its construction may be sent to The undersigned applicant for this building permit does hereby certify that he understands and accepts his obligations as an employer of labor under theFlorida Workmen's Compensation Act, being Section 5966, Compiled General Laws of Florida, Permanent Supplement, and has complied with the provisions thereof, and will require similar compliance from all contractors or sub - contractors employed by him in the work to be performed under this permit; and will post or cause to be posted for inspection on the site of the work such public notice or notices as are required by the Act. The undersigned agrees to employ only such subcontractors, on work to be performed under this pennit, as are licensed by Miami Shores Village. Remarks... (Signed).. STATE OF FLORIDA, COUNTY OF DADE. ss Before me, the undersigned authority, a notary public, duly authorized to administer oaths and take acknowledgments, personally ap- peared and who, being by me first duly sworn, upon oath deposes and says that he is the. of the above described construction, that he has carefully read the foregoing application, and that he did sign the same, and that all facts therein by him stated //()' true. l � Permit No..» ._t, 1.1 Date.._ ) ( U Read, Sworn to and Subscribed before me. Disapproved (Signed) Building Inspector MIAMI SHORES VILLAGE BUILDING INSPECTION DEPARTMENT Date to me well known, Notary Public, State of Florida My Commission Expires PLANNINC BOARD DATE Chairman Member Member Member Member ...... Member Council Approved Date Disapproved Date NOTE: A charge of $1.00 will be made for making corrections or changes to this application nfter approval has been obtained from the Planning Board. A re-inspection fee of $1.00 will be charged when such re- inspection is made necessary by improper notice for inspection or faulty materials and /or workmanship. Time & Date Called Name Date and approximate time of release Location of structure 429 N. 2. 99 St PAN AMERICAN EXTERMINATING COMPANY, INC. 275 S. W. 6th Street • Miami, Florida 33130 Dade: 854 -51 10 • Broward: 584 -4337 FUMIGATION NOTIFICATION Don, R, 1,978 Owner's name and address Holland Qom Type of structure 1 Stir C Approximate number Cubic Feet 5% Name and quantity of Fumigant MICVLO 23,E 1oF38Ldo Length of fumigation period � °� h.Tr3. Distance of nearest building 10, ft . Certified (or special I.D.) Fumigator in charge: Name Telephones 11:C3 rim 854..5110 Day 854.-5110 Night Fumigation shall be performed in strict adherence to the Fumigant's registered label and Florida State Board of Health Rules 1701 -2. Notification to be received not later than the day prior to release of the Fumigant by El County Health Department El Fire Department El Other • S P E C I F I C A T I O W S iv S for R E S I D E N C E for Mr. and lairs. Wm. A. Sykes Miami Shores, Florida Wm. D. Bordeaux, Architect 804 Langford Building Miami, Florida INDEX SPECIFICATIONS General Conditions • • • 1 - 13. Supplementary General Conditions 13-1 - 13 -2 Excavation and Grading 13 -3 Concrete and kasonry 13 -3 - 13 -5 Roofing and Sheet Metal Work . 8-5 Lathing and Plastering 13 -6 8 -7 Carpentry and :Millwork B-8 - 8-10 Hardware . 13 -10 Sash and Glazing 2-10 Tile Fork and Formica . . E3-11 Painting 13 -12 - B -13 Plumbing 13 -14 - B-17 Electrical Work . . 6 i3 -18 - B -20 • Art. 1. " 2. " 3 * 4. N 5 N " " 8. " 9. " 10. " 11. " 12. " 13. " 14. " 15. " 16. " 17. " 18 , " 19. " 20. " 21. " 22. " 23. * 24. " 25. " 26. " 27. " 28. " 29 * 30. " 31. " 32. * 33. " 34. " 35. " 36. " 37. " 38. * 39. " 40. " 41 " 42. * 43. " 44• INDEX TO THE GENERAL CONLDITIONS OF THE CONTRACT Principles and Definitions Page 1 Execution, Correlation and Intent of Documents * 1 * 1 - 2 " 2 " 2 " 2 " 2 " 2 Detail Drawings and Instructions Shop Drawings .. . .. . . . . . Drawings and Specifications of the Work . . 6. Ownership of Drawings and Liodels . . . . . 7. Samples • • • • • The Architect's Decisions . . . . . . . • Foreman Supervision Material, Labor and Appliances, , " 3 Inspection of the Work " . 3 Correction of Work Before Final Payment . . " 3 Deductions for Uncorrected Work " 4 Correction of Work after the Final Payment. " 4 Protection of Work and Property " 4 Emergencies " 4 Damage to Persons " 4 Liability insurance " 5 :Fire Insurance . . . . . . . . . . .. . . . " 5 Guaranty bonds " 5 Cash Allowances . . . . . • • • • • • • " 5 - 6 Changes in the Work " 6 Claims for Extras .. • • • • • " 6 Applications for Payment. • .. . " 6 - 7 Certificate of Payment • " 7 Payments Withheld • • • • • • • " 7 Liens. .. . • • • • . • " 7 Permits and Regulations . . • 7 Royalties and Patents " 8 Use of Premises • * 8 Cleaning Up Cutting, Patching and Digging • Delays Owner's Right to do Work . • • • • • . • • Owner's Right to Terminate Contract . . . . . Contractor's Right to Stop Work or Terminate Contract • Damage Responsibility of Contractor Separate Contract Assignment . . . Subcontractors . . Relations of Contractor and Subcontractor . . Arbitration The Architect • • It 3 " 8 " 8 " 8 - 9 " 9 " 9 " 9 " 10 " 10 * 10 * 10 * 11 • 11 - 12 " 12 - 13 * 13 Art. 41 THE GENERAL CONDITIONS OF THE CONTRACT PRINCIPLES AND DEFINITIONS: (a) The Contract Documents consist of the Agreement, the General Conditions of the Contract, the Drawings and Specifications. (b) The Owner, the Contractor and the Architect are those named as such in the Agreement. (c) The Contractor shall be responsible to the Owner for the acts and omissions of his subcontractors, and all persons directly or.indirectly employed by him or them in connec- tion•with the work. (d) The term Subcontractor includes only those having direct • contract with the Contractor or Owner and it includes one who furnishes material even though he does no work. (e) The term "person" or "anyone" as employed herein shall be taken to include a firm or corporation. (f) :Written notice shall be deemed to have been duly served if delivered in person to the individual or to a member of the firm or to an officer of the corporati on for whom it is intended, or if delivered at or mailed to the last address known to himo gives the notice. (g) The term "work" of the Contractor or Subcontractor includes labor or materials or both. (h) When the words "approved ", "satisfactory ", *equal to ", "proper ", "as directed ", etc: occur, by the Architect is understood. (i) All time limits stated in the Contract Documents are of the essence of the Contract. (j) The law of the place of building shall govern the execution of this Contract. Art. 2. EXECUTION, CORRELATION AND INTENT OF DOCUMENTS: The Contract Documents shall be signed in duplicate by the Owner and Contractor. In case of failure to sign the General Conditions, Drawings or Specifications, the Architect shall identify them. Even though the signatures of the Owner and the Contractor may have been attested by witnesses, they may be proved by any competent evidence. The Contract Documents are complementary and what is called for by any one shall be as binding as if called for by all. The inten- tion of the documents is to include all labor and materials reasonably necessary for the proper execution of the work. It is not intended, however, that materials or work not covered by or properly inferable from any heading, branch, class or trade of the specifications shall be supplied unless so noted on the drawings. 1aterials or work described in words which so applied have a well known technical or trade meaning shall be held to refer to such recognized standards. Art. 3. DETAIL DRAWINGS :dGS AIVD INSTRUCTIONS: TheArchitect shall furnish, with reasonable promptness, by means of drawings or otherwise, additional instructions necessary for the proper execution of the work. All such drawings and instructions shall be consistent with the Contract Documents, true developments -1 - Art. 3. (continued) thereof, and reasonably inferable therefrom. The work shall be executed in conformity therewith and the Contractor shall not do any work without proper drawings and instructions. The Contractor and the Architect, if either so requests, shall jointly prepare a schedule, subject to change from time to time in accordance with the progress of the work, finding the latest dates at which the various detail drawings will be required and the Architect shall furnish them in accordance with that schedule. Under like condi- tions, a schedule shall be prepared, fixing dates for the submission of shop drawings, for the beginning of manufacture and installation of material and for. the completion of the various parts of the work. Art. 4, SHOP BRAWI.'GS: The Contractor shall submit two copies of all shop or setting drawings and schedules required for the work of the various trades and the Architect shall pass upon them with reasonable prompt- ness. The Contractor shall make any corrections required by the Archi- tect, file with him two corrected copies and furnish such copies as may be needed. The Architect's approval of such drawings or schedules shall not relieve the Contractor from responsibility for errors of any sort in shop drawings or schedules. Art. 5. DttAW1: GS i1D SPEC Ir'ICi IONS GE '2HE IORK: The Contractor shall keep one copy of all drawings and specifications on the work in good order, available to the Architect and to his representatives, Art. 6. 0 1N SHIP OF DRA\PIIhGS AND .MODELS: All drawings, specifications and copies thereof furnished by the Architect are his property. They are not to be used on other work and with the exception of the signed contract set, are to be returned to him on request at the completion of the work. All Juodels are the property of the Architect. Art. 7. directed. samples. THE ARCHITECT'S DECISIONS: The Architect shall, within a reasonable time, make decisions on all claims of the Owner or Contractor and on all other matters relating to the execution and progress of the work or the interpretation of the Contract Documents. Except as may be otherwise expressly provided in or appended to these General Conditions or as particularly set forth in the Specifications, all the Architect's decisions are subject to arbitration. Art. 8, SAITLES : The Contractor shall furnish for approval all samples as The work shall be in strict accordance with the approved Art. 9 . i 0REL AN SUPLeRVISI0i' : The Contractor shall keep on the work a competent general foreman and any necessary assistants, all satisfactory to the Architect. The general foreman shall not be changed except with the consent of the Architect. The foreman shall represent the Contractor in his absence and all directions given to him shall be as binding as if given t the Contractor. On written request such directions shall be confirmed in writing to the Contractor. The Contractor shall give efficient supervision to the work, using his best skill and attention. he shall carefully study and com- pare all drawings, specifications and other instructions, and shall at once report to the Architect any error, inconsistency or omission he may discover. Art. 10. i ATRIAL, LABOR AND APPLIATNTCES: unless otherwise stipulated, the Contractor shall provide and pay for all materials, labor, water, tools, equipment, light and power necessary for the execution of the work. Art. 11. INSPECTION OF IHEWJORK: The Owner, the Architect and their representatives shall at all times have access to the work wherever it is in preparation or progress and the Contractor shall provide proper facilities for such access and for inspection. If the specifications, the Architect's instructions, laws, ordinances or any public authority require any work to be specially tested or approved, the Contractor shall give the Architect timely notice of its readiness for the inspection and the Architect shall promptly inspect it. If any such work should be covered up without approval or consent, it must, if required by the Architect, be uncov- ered for examination, at the Contractor's expense. Re- examination of questioned work may be ordered by the Architect and if found not in accordance with the Contract, all expense of re- examination and replacement shall be borne by the Contractor; otherwise it shall be borne by the Owner as extra work. Art. 12. CORRECTION OF WORK t33FORy; FINAL PAYMENT: The Contractor shall promptly remove from the premises all materials, whether worked or unworked, and take down and remove all portions of the work condemned by the Architect as failing to con- form to the Contract, and the Contractor shall promptly replace and re- execute his own work in accordance with the Contract and without expense to the Owner and shall bear all expense of all work of other contractors destroyed or damaged by such removal or replacement. If the Contractor does not remove such condemned work and materials within a reasonable time, fixed by written notice, the Owner may remove them and may store the material at the expense of the Contractor. if the Contractor does not pay the expense of such removal within five days thereafter, the Owner may, upon ten ays' written notice, sell such materials at auction or at private sale, and shall account for the net proceeds thereof, after deducting all the costs and expenses that should have been borne by the Contractor. Art. 13. DEDUCTIONS FOR UNCORRECTED WORK: If the Architect deems it inexpedient to correct work injured or not done in accordance with the Contract, the difference in value together with a fair allowance for damage shall be deducted, if acceptable to the Owner. Art. 14. CORRECTION OF `SOAK AFTER THE FINAL PAYM T : Neither the final certificate nor payment nor any provi- sion in the Contract Documents shall relieve the Contractor of respon- sibility for negligence or faulty materials or workmanship within the extent and period provided by law, and upon written notice, he shall remedy any defects due thereto and pay for any damage to other work resulting therefrom. All questions arising under this Article shall be decided under Article 9 and 43. Art. 15. PROTECTION OF WORK AND PROPERTY: • The Contractor shall continuously maintain adequate protection of all his work from damage and shall protect the Owner's and adjacent property from injury arising in connection with this Contract. he shall make good any such damage or injury, except such as may be directly due to error in the Contract Documents. Art. 16. EMERGENCIES: In an emergency affecting the safety of life or of the structure or adjoining property, not considered by the Contractor as within the provisions of Article 15, then the Contractor without special instruction or authorization from the Architect or Owner, is hereby permitted to act to prevent such threatened loss or injury, and he shall so act, without appeal, if so instructed or authorized. Any compensation claimed' due him therefor shall be determined under Article 9 and 43 regardless of the limitations in Article 23 and in the second paragraph of Article 22. Art. 17. DA1 TO PERSONS: In addition to the liability imposed by law upon the Con- tractor on account of bodily injury or death suffered through the Con- tractor's negligence, which liability is not impaired•or otherwise affected hereby, the Contractor hereby assumes, in cases not embraced . within such legal liability, to save the Owner harmless and indemnify him from every expense and liability of payment (voluntary payments excepted). • Art. 18. LIABILITY I TSURAYCE: The Contractor shall maintain such insurance as will pro- tect him from claims under Workman's Compensation Act and from any other claims for damages for personal injury, including death, which may arise during execution of this contract. Certificates for such insurance shall be filed with the Architect, if he so requires, and shall be subject to his approval for adequacy of protection. The Owner shall be responsible for his own contingent liability. Art. 19. FIRE INSURANCE: The Owner shall have insurance in effect upon the entire structure on which the work of this contract is to be done and upon all materials, tools and a'pliances in or adjacent thereto and intended for such use thereon, to at least eighty percent of the insurable value thereof. The loss, if any, is to be made adjustable with and payable to the Owner as Trustee for whom it may concern, All policies shall be open to inspection by the Contractor. If the Owner fails to show them on request or if he fails to effect or maintain insurance as above, the Contractor may insure his own interest, and charge the cost thereof to the Owner. If the Contractor suffers damage by failure of the Owner to maintain such insurance he may recover compensation under Article 37. If required in writing by any interested parties, the Owner as Trustee shall, upon the occurrence of loss, give bond for the proper performance of his duties. he shall deposit any money received from insurance in an account separate from all his other funds and he shall distribute it in accordance with the agreement as the parties interested may reach, or under board of arbitrators appoint- ed, one by the Owner, another by joint action of the other parties interested, all other procedure being in accordance with Article 43. if after loss no special agreement is made, replacement of injured work shall be ordered under Article 22. The Trustee shall have power to adjust and settle any loss with the insurers in accordance with the directions of such arbitrators, who shall also, if distribution by arbitration is required, direct such distribution. Art. 20. GUARANTY BONDS: The Owner shall have the right to require the Contractor to give bond covering the faithful performance of the contract and the payment of all obligations arising thereunder, in such form as the Owner may prescribe and with such sureties as he may approve. if such bond is required by instructions given previous to the receipt of bids, the premium shall be paid by the Contractor, if subsequent thereto, it shall be paid by the Owner. Art. 21. CASH ALLOWANCES: The Contractor shall include in the Contract Price, all allowances named in the Contract Documents and shall cause the work so covered to be done by such contractors and for such sums as the Archi- tect may direct. the Contractor in making up his bid, shall add such Art. 21. (continued) sums for expense and profit on account of cash allowances as he deems proper and no demand for expenses or profit other than those included in the contract sum shall be allowed. The Contractor shall not be required to employ for any such work persons against whom he has a reasonable objection. Art. 22. CHANGES IN THE WORK: The Owner, without invalidating the contract, may make changes by adjusting accordingly. All such work shall be executed under the conditions of the original contract exce)t that any claim for extension of time caused therewith shall be adjusted at the time of ordering such change: Except as provided in Articles 8 and 16, no changes snall be made unless in pursuance of a written order from the Owner signed or countersigned by the Architect and no claim for an addition to the Con- tract sum shall be valid unless so ordered. The value of any such change shall be determined in one or more of the following ways: (a) By estimate and acceptance in a lump sum. (b) By unit prices named in the contract or subsequently agreed upon. (c) By cost and percentage or by cost and a fixed fee. (d) If none of the above methods is agreed upon, the Con- tractor, provided he 'receives an order in writing signed by the Architect, shall proceed with the work, no appeal to arbitration being allowed from such order to proceed. In cases (c) and (d) the Contractor shall keep and present, in such form as the Architect may direct, a correct account of the net cost of labor And materials, together with vouchers. in any case, the Architect shall certify to the amount, including a reasonable profit, due to the Contractor. Pending final determination of value, payments on account of changes shall be made on the Architect's certificate. Art. 23. CLADS FOR EXTRAS: If the Contractor claims that any instructions by drawing or otherwise involve extra cost under this contract, he shall give the Architect written notice thereof before proceeding to execute the work and in any event, within two weeks of receiving such instructions, and the procedure shall then be as provided for in changes in the work. :No claim shall be valid unless so made. Art. 24. APPLICATIONS FOR PA'fl D T : The Contractor shall submit to the Architect, an applica- tion for each payment and if required, receipts or other vouchers from subcontractors showing his payments to there for materials and labor as required by Article 42. If the payments are made on valuation of work done, such application shall be submitted at least ten cbys before each payment falls due. If required the Contractor shall, before the first appli- cation, submit to the Architect a schedule of values of the various 1 Art. 24. (continued) parts of the work; aggregating the total sum of the contract, divided so as to facilitate payments to subcontractors in accordance with Article 42 (e) made out in such form as the Architect and Contractor may agree upon and if required supported by evidence as to its correct- ness. This schedule when approved by the Architect, shall be used as a basis for certification of payment unless it is found to be in error. In applying for payments, the Contractor shall submit a statement based upon this schedule and, if required, itemized in such form as the Archi- tect may direct, showing his right to the payment claimed, Art. 25. CERTIFICATE OF PAYLELT : If the Contractor has made application as above, the Architect shall, not later than the date when each payment falls due, issue to the Contractor a certificate for such amount as he decides to be properly due. Should the Owner fail to make such payment upon demand when due, the Contractor shall receive in addition to the sum named in the certificate, interest thereon at the legal rate in force at the place of building. Art. 26. PAYMENTS WITHHELD: The Architect may withhold or, on account of subsequently discovered evidence, nullify the whole or a part of any certificate for payments to protect the Owner from loss on account of: (a) Defective work not remedied. (b) Claims filed or reasonable evidence indicating probable filing of claims. (c) Failure of the Contractor to make payments properly to subcontractor or for material or labor. (d) A reasonable doubt that the contract can be completed for the balance then unpaid.. Then all the above grounds are removed, certificates shall at once be issued for amount withheld because of them. Art. 27. I,I; Neither the final payment nor any part of the retained percentage shall become due until the Contractor, if required, shall deliver to the Owner a complete release of all liens arising out of this contract, or receipts including all the labor and materials for which a lien might be filed, but the Contractor may, if any subcon- tractor refuses toflirnish a release or receipt in full, furnish a bond satisfactory to the Owner, to indemnify him against any claim by lien or otherwise. if any lien or claim remains unsatisfied after all pay- ments are made, the Contractor shall refund'to the Owner all money that the latter may be compelled to pay in discharging such lien or claim, including all costs and a reasonable attorney's fee. Art. 28. 22R1 1 TS A.00D GULhi' l ONS : The Contractor shall obtain and pay for all permits and licenses; but not permanent easements, and shall give all notices, pay all fees, and comply with all laws, ordinances, rules and regulations bearing on the work. If the drawings and specifications are at variance Art. 28. (continued) therewith, the value of any necessary changes shall be adjusted under • Article 22. if any of the Contractor's work shall be done contrary to such laws, ordinances, rules and regulations, without such notice, he shall bear all costs arising therefrom. Art. 29. ROYALTIES AND PATENTS: The Contractor shall pay all royalties and license fees and shall defend all suits or claims whatsoever for infringement of any patent rights and shall save the Owner harmless from loss on account thereof,. • Art. 30. USE OF PRE ;rIISES: The Contractor shall confine his apparatus, the storage of materials and the operations of his workmen to limits indicated by law, ordinances, permits or directions of the Architect, and shall not en- cumber the premises with his materials. The Contractor shall enforce the Architect's instructions regarding signs, advertisements, fires and smoking. The Contractor shall not load or permit any part of the structure to be loaded with a weight that will endanger its safety. Art. 31. CLEANING UP: The Contractor shall at all times keep the premises free from accumulations of waste materials or rubbish caused by his employees or work and, at the completion of the work, he shall remove all his rubbish from and about the building and shall leave his work clean and ready for use. In case of dispute the Owner may remove the rubbish and charge the cost to the several contractors as the Architect shall deter- mine to be just. Art. 32.. CUTTING, PATCHING AND DIGGING: The Contractor shall do all cutting, fitting and patching of his work that may be required to make its several parts come together properly and fit it to receive or be received by work of those con- tractors shown upon, or reasonably implied by, the Drawings and Specifi- cations for the completed structure, and he shall make good after them, as the Architect may direct. Any cost as caused by defective or ill -timed work shall be borne by the party responsible therefor. The Contractor shall not endanger any work by cutting, digging, or otherwise and shall not cut or alter the work of any other Contractor, save with the consent of the Architect. Art. 33. DELAYS: If the Contractor is delayed in the completion of the work by any act or neglect of the Owner or Architect, or any employees of either or by any other Contractor employed by the Owner, or by changes ordered in the work, by strikes, lockouts, excessive rain, storms, or other unavoidable casualties, or any other causes beyond the Contractor's 8 Art. 33: (continued) :do such extension shall be made for delay occurring more than seven days before claim therefor is made in writing to the Archi- tect. in case of a continuing cause of delay, only one claim is necessary. if no schedule is made under Art. 3, no call or claim for aeiay shall be allowed on account of failure to furnish drawings until two weeks after demand for such drawings and not then unless such claim be reasonable. Art. 34. O.TNE'-t' S AI GAT TO DC WORK: If the Contractor should neglect to prosecute the work properly, or fail to perform any provision of this contract, the Owner, after three days' notice to the Contractor, may, without prejudice to any other remedy he may have, make good such deficiencies and may deduct the cost thereof from the payment then or thereafter due the Contractor; provided, however, the Architect shall approve both such action and the amount charged to the Contractor. Art. 35. oWNEK'S KIGAT TO 'T2R dAli CU1A AAC`T': .If the Contractor should be adjudged a bankrupt, or if he should make a general assignment for the benefit of his creditors, or if a receiver should be assigned on account of his insolvency, or if he should, except in cases recited in Art. 33, persistently or repeatedly refuse or fail to supply enough properly skilled workmen or proper materials, or if he should fail to make prompt payment to subcontractors, or for material or labor, or persistently disregard laws, ordinances, or the instructions of the Architect, or otherwise be guilty of a substan- tial violation of any provision of the Contract, then the Owner, upon the certificate of the Architect that sufficient cause exists to justi- fy such action, may without prejudice to any other right or remedy and after giving the Contractor seven days' written notice, terminate the employment of the Contractor and take possession of the premises and of all materials, tools and appliances thereon and finish the work by what- ever method he may deem expedient. In such case the Contractor shall not be entitled to receive any further payment until the work is fin- ished. If the unpaid balance of the Contract Price shall exceed the expense of finishing the work, including compensation for any additional services, such excess shall be paid to the Contractor. if such expense shall exceed such unpaid balance, the Contractor shall pay the differ- ence to the Owner. The expense incurred through the Owner as herewith provided and the damage incurred through the Contractor's default, shall be certified by the Architect. Art. 36. COiv TRACT OA' S AiGhT TO 3 t Oi ;WORK OR `l, RMINA i CONTRACT: If the work should be stopped under an order of the court, for a period of three months, through no act or fault of the Contractor or of anyone employed by him, or if the Owner should fail to pay the Contractor any sum certified by the Architect, or awarded by arbitrators, then the Contractor may, upon three days' written notice to the Owner and Architect, stop work or terminate the Contract and recover from the Owner payment for all work executed and any loss sustained upon any plant or material and reasonable profit and damage. - 9 - • Art. 37 . DA,AUE : If either party to this contract should suffer damages or delay or otherwise, except as provided in Art. 38 because of any act or neglect of the other party, or of anyone employed by him, then he shall, be reimbursed by the other party for such damage. Claims under this clause shall be made in writing to the party liable within a reasonable time of the first observance of such damage, and not later than the time for final payment, except in case of claims under Art. 14 and shall be adjusted by agreement or arbitration. Art. 38. AES?O SIbILITY OF COINTRAC'TOR: Should the Contractor (see Art. 1,c) cause damage to any person (see Art. 1,e) employed on the. work, the Contractor agrees, upon due notice to settle with such person by agreement or arbitration if such person will settle. If such person sues the Owner on account of any damage alleged to have been sustained, the Contractor shall defend such proceedings at the Owner's expense. If any judgment against the Owner arises therefrom, the Contractor shall pay all costs incurred by the Owner. The Contractor, if damaged by any person held to the Owner by stipulation such as the above, agrees to settle with such person by agreement or arbitration. Art. 39. SEPARATE C01`1'1ACT: The Owner reserves the right to let other contracts in connection with this work. The Contractor shall afford other contractors reasonable opportunity for the introduction and storage of their materials and the execution of their work, and shall properly connect and coordinate his work with theirs. If any part of the Contractor's work will depend for proper execution or results upon the work of any other Contractor, the Contractor shall insect and promptly report to the Architect any defects in such work that may render it unsuitable for such proper execution and results. His failure to so inspect and report shall constitute an acceptance of the other Contractor's work as fit and proper for the reception of his work, except as to defects which may develop in other Contractor's Work after the execution of his work. To insure the proper execution of his subsequent work, the Contractor shall measure work already in place, and shall at once report to the Architect any discrepency between the executed work and the drawings. Art. 40. ASSIGi'L NT : i'either party to the Contract shall assign the contract without written consent of the other, nor shall the Contractor assign any moneys due or to become due to him hereunder, without the previous written consent of the Owner. Art. 41. SUi -CO] TRACTORS: The Contractor shall notify the Architect in writing the names of subcontractors proposed for the principal parts of the work and for such others as the Architect may direct, and shall not employ any that the Architect may within a reasonable time object to as incompetent or unfit. The Contractor shall, if so required, submit with his pro- posal a list of subcontractors selected by the Architect. if the change of any name on such list is required or permitted after signature of agreement, the contract price shall be increased or diminished by the difference between the two bids. The Contractor agrees to be fully responsible to the Owner for the acts or omissions of his subcontractors and of anyone employed either directly or indirectly by him or them, and this contractural obligation shall be in addition to the liability imposed by law upon the Contractor for bodily injuries or death through negligence in the cases covered by Art. 17 hereof. Nothing contained in the Contract Documents shall create any contractural relation uetween any subcontractor and the Owner. Art. 42. AELA'i IONS OF C 0 TRAC OR AND SUBCONTRACTOR: The Contractor agrees to bind over the Subcontractor, work- ing under general contract, 'and every subcontractor agrees to be bound by the General Conditions, Drawings and Specifications as far as appli- cable to his work, including: the following provisions of this Article unless specifically noted to the contrary in such subcontract, approved in writing as adequate by the Owner or Architect. The Subcontractor Agrees: (a) To be bound to the Contractor or to the Owner as the case may arise, by the terms of the General Conditions, Drawings and Specifications, and to assume toward them all the obli- gations and responsibilities. (b) To submit applications for payment to the Contractor, or Owner as the case may arise, in such reasonable time as to enable the Contractor (or Owner) to apply for payment under Art. 24 of the General Conditions. (c) To make all claims for extras, for extensions of time, and for damages for delays or otherwise, to the contractor in the manner provided in the General Conditions for like claims by the Contractor upon the Owner, except that the time for making claims for extra cost, as under Art. 23 froth. the General Conditions, is one week. The Contractor Agrees: (d) To be bound to the Suocontractor by all the obligations that the Owner assumes to the Contractor under the General Conditions, Drawings and Specifications, and by all the provisions thereof affording remedies and redress to the Contractor from the Owner. (e) To pay the Subcontractor upon the issuance of certificate if issued under the schedule of values described in Art. - 11 Art. 42. (continued)` 24 of the General Conditions, the amount allowed to the Contractor on account of the Subcontractor's work to the extent of the Subcontractor's interest therein. (f) To pay the Subcontractor upon the issuance of certificate, if issued otherwise than in (e) so that at all times his total payments shall be as large in proportion to the value of the work done by him as the total amount certified to • the Contractor is to the value of the work done by him. (g) To pay the Subcontractor to such extent as may be provided in the contract documents or the Subcontract, if either of these providesfor earlier or larger payments than the other. (h) To pay the Subcontractor on demand for his work or materials as far as executed. and fixed in place, less the retained percentage, at the time the certificate should be issued, even though the Architect fails to issue it for any cause not the fault of the Subcontractor. (j) To pay the Subcontractor a just sum of any insurance money received by him, the Contractor, under Art. 19 of the General Conditions. (k) To make no demand for liquidated damages or penalty for delay in any sum in excess of such amount as may be . specifically named in the subcontract. (1) That no claim for services rendered or material furnished by the Contractor to the Subcontractor shall be valid unless written notice thereof is given by the Contractor to the Subcontractor during the first ten days of the calendar month following that in which the claim originated. (m) To give the Subcontractor.an opportunity to be present to submit evidence in any arbitration involving his rights. (n) To name as arbitrator under Art. 43 of the General Condi- tions, the person nominated by the Subcontractor if the sole cause of dispute is the, work, materials, right or responsibility of the Subcontractor: or if the Subcontractor and any other Subcontractors jointly, to name as such arbi- trator the person upon whom they agree. (o) In the matter of arbitration, their rights and obligations and all procedure shall be analogous to those set forth in Art. 43 of the General Conditions. 14othing in this Article shall create any obligation on the part of the Owner to pay or to see to the payment of any sums to any .Subcontractor. Art. 43. tidBITRAT I Ov : Subject to.the provisions of Art. 9, all questions in dis- pute under this contract shall be submitted to arbitration at the choice of either party to the dispute. The general procedure shall conform to the laws of the State in which the work lies, and wherever permitted by law the decision of arbitration may be filed in court to carry it into effect. Art. 43. (continued) The demand for arbitration shall be filed in writing with the Architect, in the case of an appeal from the decision, within ten days of its receipt and in any case within a reasonable time after cause thereof and in no case later than the time of a final payment. Should the Architect fail to make a decision within a reasonable time, an appeal to arbitration may be taken as if his decision had been ren- dered against the party appealing. The parties may agree upon one arbitrator, otherwise there shall be three, one named by each party to this Contract, and the other selected by these two arbitrators, or if they fail to select a third within ten days, he shall be chosen by the presiding officer of the nearest Bar Association. Should the party demanding arbitration fail to name an arbitrator within ten days of his demand, his right to arbitration shall lapse. Should either party refuse or neglect to supply•the arbitrators with any papers or informa- tion demanded in writing, the arbitrators are empowered by both parties to take ex.parte proceedings. The arbitrators, if they deem that the case demands it, are authorized . to award to the party whose contention is sustained such sums as they shall deem proper for the tine, expense and trouble incident to the appeal and if the appeal was taken without reasonable time and cause, damages for delay. The arbitrators shall fix their own compen- sation, unless otherwise provided by agreement, and shall assess the costs and charges of the arbitration upon either or both parties. The award of arbitrators must be in writing and if in writing, shall not be open to objection on account of the form of the proceedings or the award. Art. 44. THE ARCHITECT; The.work will be under the supervision of the Architect, and whenever the word "Architect" or "Superintendent" is mentioned in these Specifications, it is understood to refer to the offices of William D. Bordeaux, Architect, .or his authorized representatives. The Architect will furnish the Contractor with plans and specifications and scale details sufficient to carry on and complete the work, but these plans and specifications are to be properly cared for and upon completion of the work returned to the Architect. Each Contractor shall set out his own work correctly and give his personal supervision, and shall have at all times some competent person on the work to act for him. WORK1i;Eiv * S TOILETS: The Contractor must provide separate sanitary water flushed toilet facilities for white and colored workmen. CLEANING AND REFITTING: The building must be kept free from all surplus material, dirt and 'rubbish at all times. At the completion of the work all paint spots must be removed from floors and walls, and all windows and doors refitted where required. All windows must be cleaned and such minor repairs and alterations made as may be necessary to make the building ready for occupancy. ciEi.ii±.AL DESCRIPTION: This work shall include the furnishing of all materials and labor required to complete the building and any supplementary work on the accompanying drawings and herein specified under the following headings: Excavation Concrete and hasonry Roofing and Sheet metal Work Lathing and Plastering Carpentry and bill `Mork Hardware Sash and Glazing Tile Work Painting Plumbing Work Electrical Work NEW GRADE: CL ENT : SAND:. STONE: • EXCAVATION AND GRADING GENERAL: All work included under this heading shall be subject to the General .Conditions of the entire operation. The subcontractor for this portion of the work is required to refer especially thereto. EXCAVA'T ING : Contractor shall excavate for trenches for footings and foun- dation walls. Surplus materials shall be removed from premises of same, and cannot be used for refilling, or back filling. How and where shown on over present grade with 10" of ish with an 8" mixture of muck house shall be raked level and slope to sidewalk. the plans, the Contractor shall fill clean, medium' rook and sand, and fin - and marl. This new grade around the shoulders rounded to make gradual CONCRETE AND MASONRY WORK INCLUDED: Under this contract,are included all. walls, floors, beams, pavements, steps and floors, and base for .tile work. All concrete block and all brickwork as indicated on the drawings. shall be by this Contractor. All cement shall be Florida Portland Cement. All. sand must be approved by the Architect. It shall be coarse, clean, sharp sand, or clean yellow gravel, free from foreign matter. All stone in concrete shall be good hard broken stone, of sizes from 1/2" to 1 -1 /2", free from dust and dirt. i3 -3 REWORCIiiG FOR COi C RET'E : Provide reinforcement steel for all reinforced concrete as shown on drawings. unless otherwise indicated, all rods shall be round steel. PROTECT IOA PRCLi WEATHER : • All work recently built must be properly protected from the elements. All work injured by the weather must be taken down and rebuilt. CHASES: This Contractor shall ascertain where all chases or open- ings for pipes, wires, ducts, etc. are to go, and not wait for such information to be given him. he shall construct all such chases as shown or required, subject to the approval of the Architect. AACHORS , This Contractor shall build in all anchors, toggle bolts, flashings, wall plugs, frames, etc. as may be required. These mater- ials shall be placed according to directions of those who furnish them. PLAIid CO:UCRETE : Plain concrete shall be mixed in the proportions of 1 part cement, 2 parts sand and 4 parts broken stone. RE I.4PORCED CONCRETE: All reinforced concrete shall be mixed in the proportions of 1 part cement, 2 parts sand and 3 parts broken stone. All concrete shall be machine mixed. .nixing to be of such duration so that cement will be uniformly distributed throughout the mass, and the concrete becoes uniform in color. FORS Before pouring concrete, the Contractor shall see that all forms are constructed so that they will be water- tight, true to line and form. The forms shall be sufficiently rigid to resist bending under load and dumping. Forms must not be removed until permission is given by the Architect. PLACING REIlvFORCE ",uE1l: Special care must be taken that reinforcing members be placed exactly in the position indicated on the drawings. CONCRETE E FOO`T'INGS: All footings indicated on drawings shall be reinforced concrete of dimensions shown. GENERAL: All work included under this heading shall be subject to the General Conditions of the entire operation. the sub - contractor for this'. portion of the work is 'required to refer especially thereto. All work must be done in, the neatest and best manner and left free from rubbish, clean and perfect upon completion. SiiEE` ' 41E AL INCLUDED: This Contractor shall provide and apply all sheet metal work, including all flashing, metal termite strips and other sheet metal work necessary to complete the work. ROOFING: ROOFING AND SHEET METAL Roofing Contractor shall provide and apply, over pine sheathing, two plies of 15# felt and one ply of 90# sanded roof- ing felt, overlaid with cement shingle tile. GENERAL: LA'TH1JAG: CO:tU ER3: V LA`1`HIiJG AND PLAST'ERIiAG All work included under this heading shall be subject to the General Conditions of the entire operation. The subcontractor for this portion of the work is required to refer especially thereto. The Contractor for this part of the work shall carefully examine all ceilings, partitions and furring, and if these are not reasonably plumb, level and solidly secured at all angles, he shall notify the Carpenter and have all such defects remedied before the lathing is commenced. ±ie shall provide all necessary labor and material, he shall do all work in the neatest and best manner, and on completion he shall remove all rubbish and leave the work clean and perfect. If, in the estimation of the Architect, the plasterer does not leave his work in the neatest and best manner, the Plasterer shall clean such work to the Architect's satisfaction or the Architect will have work properly cleaned and deduct the cost of cleaning from the Plasterer's Contract Price. After the work of all other mechanics is finished, he shall replaster all damaged portions of his work. All lathing for plaster work shall be Gypsumiock Lath, and applied according to ianufacturer's instructions. I1 CIDEETAL 1D'1'AL LATH: Clinton Cloth, tightly stretched and secured with galvan- ized staples, shall be used to cover all walls that are to be tiled and across all joints between frame and masonry construction. The lath shall be carried 6" on each side of the joint. Corners in all rooms shall be reinforced with a 12" strip of 3 -mesh galvanized Clinton Cloth. CORhER ±ADS : An approved brand galvanized corner bead shall be used for all external angles as specified on the drawings. PATEld PLASTER: All plaster, •except where otherwise specified, shall be ACES patent plaster (or equal), applied.in strict accordance with the janufacturer's direction. PATENT PLASTER: (continued) All interior plaster finish shall be smooth lime putty, true to line and free from any defects. All protruding angles shall have corner beads extending six feet (6') up from finished floor. 1& IOd PLASTER: • All exterior cement plaster shall be two coat work of the following composition: 1 part Florida Portland cement, 3 parts clear:, sharp sand and one part. lime putty containing 15% hydrated lime. TtiREE COAT FORK: All interior walls and ceilings, unless otherwise noted on the drawings or specified, shall be lathed and plastered with three coats of plaster. PA PAr(A11Olu FOR TILE: Apply Florida Portland Cement mortar under the direction of the Contractor for Tile work, as preparation for tile wainscoting in bathrooms and for tile base wherever shown on plans. (xEiNEttAL : V CARPElATRY" AND hiLL IOR& All work included under this heading shall be ejbject to the General Conditions of the entire operation. The subcontractor of this portion of the work is required to refer especially thereto. The Contractor shall furnish all rough or dressed lumber and all millwork. He shall provide all necessary wood blocks, nailing strips, plugs, door bucks, etc., and see that they are built in as required by other Contractors for their work, as the work progresses: he shall cut and frame timbers and woodwork as required by the various other trades for the completion of their work, and pro- vide all lumber required by them for scaffolding or for the protec- tion.of finished work. IATERIALS : All materials required, herein specified or shown on draw- ings, shall be the best of their respective kinds. All shall be thoroughly seasoned and shall be thoroughly protected from the weather: ROUGH LUI+1 : All framing lumber for floor joists, beams and lintels shall be x o. 1 Long Leaf Yellow Fine. All other rough framing lumber shall be lvo. 2 long leaf yellow pine. All framing lumber shall be free from loose or large knots, large shakes, excess sap, or other defects whereby its strength may be impaired. STUD TALL' S Ai D PARTITIONS: Studs in walls and partitions shall be doubled at all corners and openings, and shall be bridged once in the middle of story height. i3ridging must set back 1/2" from the face of the studs to leave a key. for the plaster. Studs abutting masonry walls shall be bolted with 3 -1/2" bolts to masonry. SUh- FLOORIv G: Lay 7/8" x 6" matched T. & G. pine sub - flooring throughout the house except where tile is specified. Sub - flooring shall be surfaced on one side, laid diagonally and securely nailed. All joints shall be properly broken, shall come over bearings to nail - ing strip on concrete joists and shall be closely butted. SHUTTERS • V l'livISHED FLOOt3ING:. All finished wood floors are to be 13/16" x 2 -1/4" Select White Oak. Flooring Contractor shall properly sand floors and finish same as specified under "PAIi'T'Ii'G ". WALL F UdRIiv G : Fur the inner side of all masonry walls that are to receive finished plaster work, with 7/8" x 2" furring strips spaced 16" on centers. EX'TEAIOR WOODWORK: Door frames and all other exterior woodwork shall be of the best quality, clear cypress free from knots, sap or other defects. It shall be sandpapered smooth and left clean and perfect upon completion r eady for the painter's finish. All windows are to have one set of shutters each, con- structed of 3/8" thick plywood framed with 5/8" x 3" Cypress. DOOR SCREENS: All exterior doors shall be fitted with 18 -mesh bronze wire screens set in 1 -3/8" wood frames. liv TERI OR JOOD gORK : All interior woodwork shall be Ivo. 1 grade Fir, free . from knots, sap or other defects. KITCHEN CABINETS: Cabinets to be built according to details, where shown in Kitchen. :backs are to be tempered presswood and doors are to be of 3/4" plywood. Doors are to be flush with front of cabinets. L"iivEN CLOSET: Linen closet shall have 1 -1/8" x 11 -5/8" shelves, approx- imately 10" apart, running to a height of 7 feet from the floor. EDIClivE CABIANET : Provide indicated, one No. Ketcham Mfg. Corp. and set flush with the wall in each bathroom where 520 L. medicine cabinet as manufactured by G. Ili. , complete with side lights. 13 -9 CLOSET P ITLL GS AYD St ;LViiiG: Each Bedroom Closet shall have 7/8" x 16" shelving running the length of the closet and supported on wall cleats. Hanger rods shall be 3/4" chromed iron pipe supported on flanges. Provide shoe rack in the master bedroom. Closet wardrobe to be as detailed. DOOR AND BASE TRIM: All trim shall be made in strict accordance with the details shown. HARDWARE Hardware to be furnished by the Owner. SASH AND GLAZ IN G WORK INCLUDED: Sash shall be THORN casement type with bronze screens, 18 -mesh wire. Glass to be double strength, set in approved putty. Plate glass windows shall be 1/4" plate glass, lvo. 1 grade free from all defects or discolorations, and set in stainless steel frame, abutting steel sash. '1ILE: GEI1RRAL : DRAINBOARD: Formica. TILE WORK All tile used except wainscoting in be cement tile. ftinscoting shall be encaustic high above floor and 6' -Ow above tubs. Cement tile used, except white tile shall have Spanish color - design. FORMICA. This Contractor shall furnish all labor and materials necessary to install tile as shown on plans. WORK TO BE I CLUDED : All window sills, except Laundry andMaidts quarters shall be of tile. Bathroom floors and wainscoting; floor of rear louige room; kitchen steps, porch and service entrance; main entry, steps; and front sidewalk shall be of tile. bathrooms, shall colored tile 4f -0" for sidewalk, Kitchen sink drainboard and splash shall be of • GENERAL: All work included under this heading shall be subject to the General Conditions of the entire operation. The subcontractor for this portion of the work is required to refer especially thereto. All woodwork must be thoroughly clean and dry before any paint or stain is applied. it shall be rubbed smooth, and all knots and sappy places shall be covered with grain alcohol shellac before painting. All woodwork that is to be painted shall be primed at the earliest possible moment. The back as well as the front of all millwork coming in contact with masonry walls shall be priried. After priming, all nail holes, cracks, etc., shall be puttied with putty colored to match the finish. ho coat of paint shall be applied until the under -one is perfectly dry. All mouldings shall be carefully cleaned out before each coat of paint is applied. All finished surfaces shall be left smooth and even and free from brush marks or other defects. On completion, this Contractor shall remove all spots from floors, glass, etc., and shall repaint edges of sash and doors where necessary after fitting by the Carpenter. SAEPLES :. PAINTING Samples of all finishes shall be made for the Architect's approval, and must be accurately matched by the finished work. MATERIALS,: All materials specified shall be brought to the building in the original packages, which shall remain unopened until inspected unless specifically approved by the Architect. White lead shall be best American white lead of an approved brand. Linseed oil shall be pure and of best quality, raw or boiled as may be required. Putty for exterior work shall be pure linseed oil putty; for interior work, white lead putty. Shellac shall be best grain - alcohol shellac. EXTERIOR iETAL AND IRON WORK: All sheet metal and iron work including drip strip and exposed flashing, shall receive two (2) coats of red lead and a finish coat of lead and oil to match stucco. EXxERIOR S'T'UCCO: All exterior stucco and exposed concrete blocks or bricks shall be given two coats of waterproofing. • EXTERIOR WOODWORK: The entire woodwork, including front door, shall be primed, puttied and given three good coats of lead and oil in selected colors. Sandpaper between coats. i1VTERIOR PAINTED WOODWORK: All interior woodwork shall be primed, puttied and finished with three coats of lead and oil in colors selected. All woodwork in Living Room and Dining Room shall be glazed. Sandpaper between coats. emulsion. INTERIOR PAINTED PLASTER: Plaster walls and ceilings in Kitchen and Bathrooms shall be painted three coats of oil paint. OAK FLOORING: Finishing of Oak Flooring shall be executed by the Flooring Contractor. All oak floors shall be scraped and machine sanded, followed by one good application of filler. All oak floors shall be finished with two coats of grain- alcohol shellac, and one coat finally of wax thoroughly polished. LUt ER TREATMENT: All under floors shall be sprayed with one coat of asphalt r GE AXRAL : PLUEBING 1 All work included under this heading shall be subject to the General Conditions of the entire operation. The subcon- tractor for this portion of the work is required to refer espec- ially thereto. These specifications are intended to provide a complete and perfect system of hot and cold water supply, drainage, vent piping, etc. Anything indicated on the drawings and not speci- fied vice versa, or any detail omitted which is necessary to the proper installation of the system, must be supplied and installed by this Contractor without extra charge. The Contractor will be held strictly responsible for the quality of the materials and labor furnished and for the proper installation of the system; he must maintain a competent foreman at the building throughout the progress of the work. All work shall conform to the Mules and Regulations of the Local .oard of Health and the requirements of the rlumbing Code. PEt3i :I T:i AND COia'JEC'T IONS : This Contractor shall file all drawings, pay all fees, and obtain and pay for all permits. He shall see that an adequate supply of water for building purposes is provided at the commence- ment of the operation. J;XCAV A'1' I ON : Excavate and back -fill as may be necessary for water - supply piping, soil line and drainage systems. LES1S : This Contractor shall make all tests as called for in the Plumbing Code or Regulations, in the presence of the Architect or his representative. Any leaks that may appear shall be repaired by the Contractor without extra charge, and the tests repeated until the piping is shown to be properly tight. CAST IRON PIPE: All cast iron pipes, traps, fittings, etc., underground shall be "extra heavy "; all above ground "medium ".. They shall be factory tested, free from sand holes, splits and other defects, and of uniform weight and thickness. 0 FLASHING OP ITENT PIPES. Where vent pipes pass through the roof, the joints shall be made watertight with approved special flashings or sleeves of six -pound sheet lead enclosing the pipe on all sides. SEPTIC TANK: Provide and install where shown on the drawings, a 700- - gallon septic tank, complete with all baffle - boards, piping and 125 feet of drain tile, etc. HOUSE SEWER: The house sewer shall be of 4" cast -iron pipe, run as shown on drawings and discharging into the concrete main leading to septic tank. All bends and changes in direction shall be made with long sweeps, and under no circumstances shall any part have a pitch of less than 1/8" to the foot. SOIL AND VENT PIPS: Soil stacks shall be of "medium" weight and cast -iron pipe, properly.connected with the house drain and carried up full size through the building and above the roof. All offsets shall be made at an angle of not less than 45 degrees to the horizontal. All turns shall be made with large bends and all branches with Y's. No lead bends are to be used except for waterciosets. Pipe stacks shall be firmly supported at the base on masonry or other approved manner, and elsewhere on approved iron hangers. CILEAISTO U'T S : Readily accessible cleanouts shall be placed on all horizon- tal lines, and at the base of all risers. IAS.LE PIPES: The size of waste pipes, unless otherwise specified, shall be as follows: water closets 4 ", sinks 1 -1/2" and all other fix- tures 1 -1/4 ". TRAPS AND VENTS: Every fixture shall have an approved trap, back - vented in accordance with the local sanitary requirements. WATER SUPPLY: The water supply shall be taken from the water company's main as indicated on the drawings. This Contractor shall have proper lead connections made and shall pay for same; from this he shall continue with 1" pipe to the inner face of the foundation wall. Provide shut -off valve at outside face of building. HOSE BIB I3S : Provide and install hose bibbs where indicated on drawings with valves on face of wall. HOT WATER SYS'TEt Provide and install one 52- gallon General Electric Automatic Control Hot Water Heater. PROTEC ' IOh OF FIXTURES: Immediately after the setting of any fixture, fitting or piping, this Contractor is to protect it adequately against damage. He will be held responsible for all fixtures until they are accepted by the Architect. Any fixture or fitting that becomes damaged is to be replaced by this Contractor without extra cost to the Owner. At all stages of the installation, pipe openings must be"protected against the entrance of foreign material. ANGLE VALVES: All fixtures shall have separate shut -off valves, placed in easy access. FIXTURES: Provide and set all fixtures and fittings necessary to complete the plumbing system whether herein specially mentioned or not, in accordance with the following schedule. The numbers given below refer to the fixtures manufactured by Standard Sanitary Manufacturing Company. Fixtures in the estima- tion of the Architect which are equal may be substituted. Colored fixtures to be used in Master Bathroom only. Tub and Shower Combination: Plate ' -2225, 5' -0" B -348 bath fitting and B -158 shower fitting B -438 waste Chrome curtain rod (Omit in Master Bathroom.) Shower Servant's bathroom: Plate i3 -170, complete with chrome drain. Lavatories: Plate F -126, 20" x 18" W.H. supplies 1 -1/4" C.P., 179 -Trap 1 r ?IXTUiES: (continued) Water closets: Plate F -2045 Kitchen Sink: Plate P -7020, 36" x 20" B -906, swing -spout faucet, B -989 strainer. P1 -17 -G, 1 -1/2" chrome plated trap. Sink to have separate outlet for G. E. Disposall. Dish ~Washing; machine: Dish Washer to be G. E., A.E.748 completely connected in accordance with Local Plumbing Code. Opening in Drain Board to be provided by Drainboard Contractor. Double laundry Trays: To be each 16" x 24" cast -iron enameled tub, mounted on cast iron adjustable legs and frame. Tub enclosure - aster Bathroom: Glass enclosure around tub in ivaster Bathroom, only, shall be of chrome frame and vented top. Washing achine: To be G. E. Type and model to be selected by the Owner. Contractor to provide hot and cold water supplies with chrome hose -bibb faucets. GENERAL: "ErraCTRICAL WORK . All work included under this heading shall be subject to the General Conditions of the entire operation. The.subcontr.ctor for this portion of the work is required to refer especially thereto. These specifications are intended to provide for a complete and perfect wiring system of electrical wiring. Anything indicated on the drawings and not specified, or vice versa, or any detail omitted which is necessary to the proper installation .of the system must be supplied and installed by this Contractor without extra charge. This Contractor shall pay for all permits and connections, and all inspector's fees. • Es shall be responsible for any injury to his work from any cause, until accepted by the Architect. He shall comply with all requirements of the local authorities, the Public Service Corpora- tion supplying the current, and the Board of Fire Underwriters. He shall place all necessary thimbles and outlet boxes which occur in masonry work, before this wdrk is done, or shall do such cutting and repairing as may be necessary at his own expense and to the approval.of the Architect. No cutting of joists or studs shall be done without first securing, permission from the Architect. :A'TERIALS : All wires, switches, fittings, etc., shall be such as are found in the list of approved fittings of the National board of Fire Underwriters. Samples of all material to be used.on the work shall be submitted to the Architect for his approval. LOCATION OF The locations of outlets are shown on the Architect's draw- ings, but must be verified by the Architect at the building before the outlets are placed. Slight changes in the position of outlets, if decided upon before any work has been done by this Contractor shall be made by him without extra charge. Upon completion, the Contractor shall test the system in the presence of the Architect. The installation must be such that between the service switch and the most remote fixture not more than 2 percent drop may be found under full load. PANEL BOARD: : Provide and set where indicated on drawings, a fully equipped Square -D fuseless multi - breaker panel board of the required number of circuits. B-18 COLIDUil' WORK: All wiring throughout shall be in rigid galvanized iron conduit. Conduits must in no case be fastened to gas, water or other pipes, and shall be kept not less than 5" away from hot water pipes. mE'T'AL TUBE CaDUI`i'S : All metal tube conduits shall be installed behind plaster of walls and in floor construction and so run that the wires may be withdrawn at any time. The inner diameter of all conduits shall be 0 larger than the combined diameter of the wires contained, and in no case shall it be smaller than 5/8 ". All ends of conduits shall be squarely cut with hack saws, the use of cutting wheels will not be allowed. Conduits shall be reamed out clean before being put together. Conduits shall run as nearly straight as possible between outlets and switches. There more than three bends are required, an intersection or junction box shall be introduced to relieve the strain in pulling the wires. OUTLETS: 'miring shall terminate at all cutlets in stamped galvanized steel outlet boxes of approved make, and'aimilar finish to conduit. Outlet boxes shall be located where directed, set so that the plates will be flush with the finished wall or baseboard, and protected from injury by the plasterers or other workmen. 'Whhere two or more switches are located side by side they shall be set in a gang box. FIXTURE SUPPORTS: Boxes for fixture outlets shall have suitable studs for the support of the fixtures, so arranged that the weight of the fixture will not come on the outlet box. TIRE: All wire and cable used throughout shall be 98 percent pure copper, rubber covered and with braided insulation as approved by the ivational Board of Fire Underwriters. No wire smaller than ho. 14 B. & S. gauge shall be used. All wires larger than No. 6 inclusive shall be stranded, MIRE J O1h T S :. Joints and splices will only be permitted at junction or outlet boxes, never inside conduits. All joints shall be firmly soldered without acid, and taped, first with rubber tape and then with friction tape equivalent in thickness to the insulation of the wire. a SWITCHES: All switches shall be "Bryant" tumbler switches with compo- sition plates of finish to match adjacent hardware. Switches must be of the highest quality in type and workmanship, and must be approved by the Architect. Install three —way switches where marked on drawings. Where two or more switches are located side by side, they shall have one single plate. FIXTURES: Allow the sum of $125.00 to cover the cost of fixtures which will be selected by the Architect and installed by the Wiring Contractor. RECEPTACLES: Provide and install where noted on drawings, "Bryant" flush receptacles of the pin type with plates and with same finish as switch plates. ELECTRIC CHINE CIRCUITS: Provide and install as shown on drawings two, three -tone chime systems. This Contractor shall supply and install chimes properly with an approved transformer. OUT'SIDB TELEPHONE SERVICE: Run conduit, to be approved by the Telephone Company, from the exterior wall, where directed, to outlets, with approved face plate at outlet. Leave a No. 14 wire in conduit for pulling in future telephone wires. x. 20 r STATE OF FLORIDA) S3 COUNTY OF DADE ) 9 7-22-L ` V State of Florida, b duly sworn, doth depose and says that under the provisions of Section B -368, Sub - section (d), of the Building Code of Miami Shores Village /// he desires to build l /(, `ie Vd://1/4e, on Lot y / Blocky of e __ subdivision; that he is the owner of said property, and will do the work personally, and that he will, at such times as are required by the Zoning and Building Directors - 1. File plans and specifications and obtain approval of Village Planning Board and o$ the Building Inspector. 2. Apply for and secure a permit. 3. Pay the required fees for license and for permit. 4, Execute the work in accordance with the provisions of the Zoning, Building, and Electrical (odes of Miami Shores Village. 5. Apply for jnspecrtions. 6. File with the Btdlding Inspector certificates that provision has been made to carry the necessary Workman's Compensation, Public Liability and froperty Damage Insurance. File with ,the fi.dlding Inspector as the job progresses certificates showing the payment requirod by the Federal Social Security Act to the State of Florida or the ?United States of Jmerica, 8. Assume the responsibility of not employing contractors or sub - contractors other than. those properly licensed by Miami Shores Village or any part or portion of the acrk including, but not limited to, general contracting, Plumbing, hea:•ing, elect^ical,- septic tank, solar system, lathing, tile, terrazo, painting, roofing and sheet metal work or installation. 9. Not`sot himself up as a "Contractor ". 10. Execute Builder's Bond. (k).01A.L.,4,,,,,4.4. 1. And further this Deporent says not. . Signature of Applipant. Signature of Officer administering oath. the Village of Miami Shores, County of Dade and l ��in SUBSCRIBEI AND SWORN Tp BEFORE ME THIS DAY of 2. y A. D., 19 SO