Loading...
RC-18-1122 (2)IRL IBA 2 Miami Shores Village 10050 N.E. 2nd Avenue NE Miami Shores, FL 33138-0000 F' Phone: (305)795-2204 LORtDp' Permit NO. RC-4-18-1122 Permit Type: Residential ConstructionPeritWorkClassification: Alteration Permit Status: APPROVED Issue Date: 5/1/2018 1 Expiration: 10/28/2018 Project Address Parcel Number Applicant 240 NE 97 Street 1132060134020 PROPERTY ACES LLC Miami Shores, FL 33138- Block: Lot: Owner Information Address Phone Cell PROPERTY ACES LLC 240 NE 97 Street MIAMI SHORES FL 33138- 240 NE 97 Street MIAMI SHORES FL 33138- Contractor(s) Phone Cell Phone VENUR CONSTRUCTION, LLC (305)903-1795 Valuation: $ 70,000.00 Total Sq Feet: 0 Approved: In Review Comments: Date Approved:: In Review Date Denied: Type of Construction: REMODEL KITCHEN AND 2 BATHR Occupancy: Single Family Stories: Exterior: Front Setback: Rear Setback: Left Setback: Right Setback: Bedrooms: Bathrooms: Plans Submitted: Yes Certificate Status: Certificate Date: Additional Info: Bond Return : Classification: Residential Fees Due Amount CCF 0.00 DBPR Fee 0.00 DCA Fee 0.00 Education Surcharge 0.00 Notary Fee 5.00 P&Z Review Fee 0.00 Permit Fee 1,050.00 Scanning Fee 3.00 Technology Fee 0.00 Total: 1,058.00 Pay Date Pay Type Amt Paid Amt Due Invoice # RC-4-18-67332 04/27/2018 Check #: 122 $ 50.00 $ 1,008.00 05/01/2018 Credit Card $ 1,008.00 $ 0.00 Available Inspections: Inspection Type: Window Door Attachment Framing Insulation Drywall Screw Final PE Certification Window and Door Buck Fill Cells Columns Review Building Review Planning Review Electrical Review Plumbing Review Structural Review Mechanical In consideration of the issuance to me of this permit, I agree to perform the work covered hereunder in compliance with all ordinances and regulations pertaining thereto and in strict conformity with the plans, drawings, statements or specifications submitted to the proper authorities of Miami Shores Village. In accepting this permit I assume responsibility for all work done by either myself, my agent, servants, or employes. I understand that separate permits are required for ELECTRICAL, PLUMBING, MECHANICAL, WINDOWS, DOORS, ROOFING and SWIMMING POOL work. OWNERS AFFIDAVIT I certify that all the foregoing information is accurate and that all work will be done in compliance with all applicable laws regulating construction andrOTinci. Futhermore. I authoiizc the above -named contractor to do the work stated. May 01, 2018 Authorized Signa ure. Owner / Applicant / Contractor / Agent ware Building Department Copy May 01, 2018 1 Miami Shores Village RLCEIVEDM1 o Building Department APR 27 2019 10050 N.E.2nd Avenue, Miami Shores, Florida 33138 J Tel: (305) 795-2204 Fax: (305) 756-8972 INSPECTION LINE PHONE NUMBER: (305) 762-4949 S FFB/ C 201 BUILDING Master Permit No. `w ZZ PERMIT APPLICATION Sub Permit No. UILDING ELECTRIC ROOFING REVISION EXTENSION DRfNEWAL PLUMBING MECHANICAL PUBLIC WORKS [A CHANGE OF [:]CANCELLATION SHOP CONTRACTOR DRAWINGS JOB ADDRESS: 2-q'0 me 6)3 4re-e -1]' City: Miami Shores County: Miami Dade zip:i Folio/Parcel#: 7 0c - OI 3 1" 7 ©,>— O Is the Building Historically Designated: Yes NO C Occupancy Type: Load: Construction Type: Flood Zone: BFE: FFE: OWNER: Name (Fee Simple Titleholder):R-op.Tli Ce L-Z_G Phone#: C )zIdLaa0 Address: C% -q City: I i \--P _c Tenant/Lessee Name: Email State: Phone#: 3lt i'z CONTRACTOR: Company Name: NU C00N5 T UC, Phone#: Address: 2t,3-5o wcvF o9 <r LA.-riT toz City: ffiA'IV_Y State: Zip: Otis , Qualifier Name: D4-n-'1 BA Phone#: 305- ?94?- State Certification or Registration #: Certificate of Competency #: DESIGNER: Architect/Engineer: b\9-oyuy- aSS Phone#: Address: f;7Zol Stu G"y City: State:_t7L Zip: ©2 Value of Work for this Permit: $ 30,200 Square/Linear Footage of Work: Type of Work: Addition Alteration New Repair/Replace Demolition vs• Specify color of color thru tile: Submittal Fee $ Permit Fee $ " CCF $ CO/CC $ Scanning Fee $ 3 Technology Fee $ Structural Reviews $ C50 Radon Fee $ DBPR $ Training/Education Fee $ Notary $ Double Fee $ A, Bond $ TOTAL FEE NOW DUE $ ki COB. CK) Revised02/24/2014) Bonding Company's Name (if applicable) Bonding Company's Address City State Mortgage Lender's Name (if applicable) Mortgage Lender's Address City State Zip Zip Application is hereby made to obtain a permit to do the work and installations as indicated. I certify that no work or installation has commenced prior to the issuance of a permit and that all work will be performed to meet the standards of all laws regulating construction in this jurisdiction. I understand that a separate permit must be secured for ELECTRIC, PLUMBING, SIGNS, POOLS, FURNACES, BOILERS, HEATERS, TANKS, AIR CONDITIONERS, ETC..... OWNER'S AFFIDAVIT: I certify that all the foregoing information is accurate and that all work will be done in compliance with all applicable laws regulating construction and zoning. WARNING TO OWNER: YOUR FAILURE TO RECORD A NOTICE OF COMMENCEMENT MAY RESULT IN YOUR PAYING TWICE FOR IMPROVEMENTS TO YOUR PROPERTY. IF YOU INTEND TO OBTAIN FINANCING, CONSULT WITH YOUR LENDER OR AN ATTORNEY BEFORE RECORDING YOUR NOTICE OF COMMENCEMENT." Notice to Applicant: As a condition to the issuance of a building permit with an estimated value exceeding $2500, the applicant must promise in good faith that a copy of the notice of commencement and construction lien law brochure will be delivered to the person whose property is subject to attachment. Also, a certified copy of the recorded notice of commencement must be posted at the job site for the first inspection which occurs seven (7) days after the building permit is issued. In the absence of such posted notice, the inspection will not be approved nd a reinspection fee will be charged. Signatur Signature OWNER or AGENT CONTRACTOR The foregoing instrument was acknowledged before me this day of 20by whdl' s persopgf c own to me or who has produced as identification and who did take an oath. NOTARY PUBLIC: Sign. Print: Seal: MY COMMISSION # GG 044602 Bonded Thru Notary Public Underwriters The foregoing instrument was mow dged before me this8 2' dayofI L- 20 113, . by who is personally known to me or who has produced as identification and who did take an oath. NOTARY PUBLIC: Sign: J. r- • % rvorary r'ublrC State of Florida Seal: Nicolas H Vera c: My Commission GG 183788 w w Expires o2/o7/2022 APPROVED BY Plans Examiner Zoning Structural Review Clerk Revised02/24/ 2014) Miami Shores Village Building Department 10050 N.E.2nd Avenue Miami Shores, Florida 33138 Tel: (305) 795.2204 Fax: (305) 756.8972 CHANGE OF CONTRACTOR / ARCHITECT Permit N. Owner's Name (Fee Simple Title Holder): ?v-o .7 I e Z45- Phone #: _IV-S 6eE-+6 q- d Owner' ddress: q --` b Sc o City: State : L_ Zip Code:'3 / Job Address (Of where work is being done): 2 LyO /( %z—=- % S City: Miami Shores State: —Florida Zip Code: Contractor' s Company Name: (/c,./', vim— Phone #: Address: JJW City:` Qualifier' s Name: Zip Code: O(, Lic. Number: C 061 < G Architect/ Engineer of Record Name: o cPhone #: Address: St City: State: L Zip Code: 33y2-- Describe Work: j C —v , I c_ L v`_ / , l i cj, - hereby certify that the work has been abandoned and/or the contractor/architect is unable or unwillin to complete the contract. I hold the Building Official and the Miami Shore harmless of all legal involvement. Signature Signature Owner or Agent Contractor or Architect The foregoing instrument was aknowledged before me thisiday of20y i Who is personally known tg me or h p o c d V+CIS as indentification. t :: MAHARAI K. GONZALEZ MY COMMISSION # GG 044602 a; EXPIRES: November 2,2020 0n ed Thru Notary Public Underwriters Seal: The foregoing instrument was aknowledged before me this day of , 20 by who is personally known to me or who has produced Notary Public: Sign: Seal: as indentification. Miami Shores Village Building Department 10050 N.E. 2No Avenue Miami Shores, Florida 33138 Tel: (305) 795.2204 Fax: (305) 756.8972 Change of Contractor/Architect or Engineer A change of contractor, architect or engineer must be done under a permit number. There is a $75.00 charge for a change of contractor. The owner will submit a Change of Contractor Form completed with notarized signatures. If the signature of the previous contractor cannot be obtained the owner must send a certified letter/return receipt notifying the previous contractor, architect or engineer the reason for the change. The owner must allow 10 business days for the contractor, architect or engineer to respond. A permit application must accompany the change of contractor form, with the information and signature of the new contractor. The new contractor must be registered with the Village or must submit the required documents to register with the Village. 1. Change of Contractor form completed, signed and notarized. 2. Permit application by new contractor. 3. Required fees. 4. Copy of original letter sent via certified mail along with the returned receipt. In addition to the requirements above the architect or engineer of record must authorized the new architect or engineer to reproduce his documents. The authorization must be in writing and must be signed and sealed. DI,PACES April 02 2018 Via U.S. Certified Mail IMW Construction 6538 NW 28 Ct Margate, FL 33063 Attn: Ian McLean Walker RE: Independent Contractor Services Agreement dated May 12, 2017 between SH Improvement, LLC and Property Aces, LLC, as amended (the "Contract") Mr. Mclean: By means of this letter, we notify you, as Qualifier of SH Improvement and IMW Construction that the contract named above has been terminated and all settlement documents have been signed by your representant Mr. Raphael Baruch. We are here informing you that you will no longer be our Contractor for any repair to the house at 240 NE 97th St, Miami Shores, FL 33138. All rights and remedies are hereby reserved against you. Sincerely, ELEAZAR LOPEZ-CONTRERAS Manager Property Aces, LLC 9740 SW 72 Ave. Pinecrest, FL. 33156 1786 8784730 / +1786 8784696 www. property-aces.com X of I m1.d m jr p- PO "tom . 11 (31L 330b3 t F_ Ir certified Mail Fee PINECREST N $ $3.45 E 0099, 11301 S DIXIE HWY Extra ervices ees(d.0ba-1, ddtee 1 MIAMI 0 ReturnR"PtQWWO h S - ,.-_ `'Ti `FL o Return Reoelpt (eleetoNo) $ — $0.0 7— lP"W'ar 33256-9998 o C-1- — R-1l-d Deg_ $ — — i 1158950099 p ndanslyoetueRegetea S __$0 00— ` t J . " 04/02/2018 (800)275-8777 5:14 PMndunsignat—ReWktedDWK-y 0 ' Postage L0.517 GSp o Tom Postw and 174 8 ,t2p Product Sale Final 6.70 Description Oty Price co Sent To — — — r%gwco First -Class i a TAlv MeG u VA'CK-i/L -crS]-t-7 $0.50 sr---i an?Apt riro., i rso 9&--------- Mai 1 rv0Y y 0— Ir Letter eA Domestic> POMPANO BEACH, FL 33063) ems cam' (Weight:0 Lb 0.50 Oz) Estimated Delivery Date) Wedn Q,[u4 8) e-'( 17@0180040000071939311) ed 6,— '_ —$ 3., 45 f1 USPS Certified Mail #) eleQ11-- o-, Total ----- — $ 5.45 Cash - --_. $ 20.45 Change ($ 15.00) Use label # $LabelNumber$ for inquiry on Return Receipt (Electronic). Text your tracking number to 28777 2USPS) to get the latest status. Standard Message and Data rates may apply. You may also visit USPS.com USPS Tracking or call 1-800-222-1811. In a hurry? Self-service kiosks offer quick and easy check-out. Any Retail Ass6ci afe cw[—§hbw, you `how. For Return Receipt (by email), visit USPS. com, Track 8 Manage to track your item. Under Available Actions select Return Receipt Electronic", enter Your name and email address. All sales final on stamps and postage Refunds for guaranteed services only Thank you for your business HELP US SERVE YOU BETTER TELL US ABOUT YOUR RECENT POSTAL EXPERIENCE to: https:// p alexperience.c /Pos 840- 0-0110-003-00028-52 2-02 or scan this code with Your mobile device: ANUNITED STATES POSTAL SERVICE Date: April 16, 2018 Mabelly Leon Ponte: The following is in response to your April 16, 2018 request for delivery information on your Certified MaiITM item number 70180040000071939311. The delivery record shows that this item was delivered on April 4, 2018 at 3:57 pm in POMPANO BEACH, FL 33063. The scanned image of the recipient information is provided below. Signature of Recipient : Address of Recipient: Thank you for selecting the Postal Service for your mailing needs. If you require additional assistance, please contact your local Post Office or postal representative. Sincerely, United States Postal Service CE1 VC, INDEPENDENT CONTRACTOR SERVICES AGREEMENT NON -EMPLOYEE COMPENSATION CONTRACT) APR 2 1018 This Independent Contractor Services Agreement (the "Agreement") is entered into on this April 26, 2018 by and between Ve ur Construction, LLC a Florida limited liability company ("Contractor") and Property Aces, LLC, a Nevada limited liability company Client") for services to be rendered at 240 NE 97`" St. Miami Shores, FL 33138. Contractor shall complete the Scope of Work attached 61 days from the day the Renovation Permit(s) is(are) approved by the City. The parties agree that the Contractor shall manage its time and resources at will. Further, the parties agree that any delay in payment may result in a suspension of activity and a matching extension of time to complete the Scope of Work. Contractor and Client hereby agree to the following: 1. Independent Contractor: Contractor and Client intend this Agreement to be one of independent contractor and client. Accordingly, Contractor retains the sole right to control or direct the manner in which the services prescribed herein are to be performed. Subject to the foregoing, Client retains the right to inspect, to stop work, to prescribe alterations, and generally to supervise the work to insure its quality and conformity with that specified in this Agreement. Contractor and Client understand that it is the Contractor's sole and complete responsibility to pay all employment taxes, including Federal and State withholding taxes and Social Security, and to obtain insurance, including worker's compensation coverage and public liability insurance and property damage insurance arising out of or relating to this Agreement. Contractor warrants that upon signing of this Agreement that Contractor has obtained all stated and necessary insurance and that it shall be kept in full force and effect until the completion of the work contracted for herein, and that the Property shall be named as an additional insured on all of the Contractor's insurance policies. The terms of this Agreement shall apply to and encompass all services rendered by any/all sub -contractors performing services on behalf of the Contractor. To the fullest extent permitted by law, the Contractor shall indemnify and hold harmless the Client, Client's representatives, agents and employees from all claims, losses, damages and expenses arising out of or resulting from the performance of the work, including but not limited to any such claim, loss, damage or expense caused in whole or in part by any negligent act or omission of the Contractor, anyone directly employed by them or anyone whose acts they are liable for. 2. Services Provided: Contractor agrees to perform the services listed in this contract (as contained in Exhibit "A", attached hereto and made a part hereof by reference) on behalf of the Client. 3. Project Cost Estimate: Pre -construction estimates for construction costs and coordination are approximately Thirty Thousand Two Hundred Dollars, (S30,200.00). The Contractor shall use the Contractor's best efforts and make every effort possible to keep costs of construction with stated budget and in an event the costs surpass estimates, the Contractor will follow the rules of change orders, stated in this document. 4. Taxes and Building Permits: The Contractor understands and agrees that he shall be responsible for all taxes, fees and expenses imposed directly or indirectly for its work, labor, material and services required to fulfill this contract. The Contractor is responsible for all permits pertaining to the law, ordinances and regulations where the work is performed. 5. Inspections: The Contractor shall call for all building inspections, meet with the inspectors, and ensure that all work contemplated herein passes all required building inspections. The Contractor shall pay for the entire cost of any re -work resulting from a failed inspection. If the Contractor fails to pay for any re -work inspection costs, the Client may deduct the reasonable costs against any sums due to the Contractor. 6. Clean-up: Contractor will be responsible for cleaning up the job on a daily basis, including all generated construction debris, drink cans, food wrappers, and/or other trash. 7. Client Approval: Client will approve Contractor services on the following basis: a. The services meet all governing building codes. b. All required building permit inspections have been completed and passed. c. The services have been completed including all punch -out work as agreed. 8. Invoicing and Payments: See the payment schedule as contained in Exhibit "B", attached hereto and made a part hereof by reference. I,PkERTSY PROPERTY ACES, LLC 9740 SW 72"d Ave. Pinecrest FL, 33156 Phone: 786-8784696; Email: inforlproperty-aces.com 9. Change orders: The Parties understand and agree that no change orders or contract additions may be made unless agreed to in writing by the Client and Contractor. If any additional work is performed and not covered in this Agreement, the Contractor proceeds at the Contractor's own risk and expense and hereby waives any rights to reimbursement or contribution from the Client, in addition to waiving any other rights that may become available to the Contractor to be compensated for the additional work. 10. Cancellation: If the Contractor does not fulfill its responsibilities as stated in this contract or does not delivers the offered quality of his work, the Client may, without any further obligation cancel any of the services in this contract which have not been completed or which have not yet been started by the Contractor. Upon such cancellation, the Contractor shall only be entitled to compensation for the work performed. 11. Penalties: If the Contractor delays completion of the work beyond IS days by causes directly imputable to his performance, the Client may reduce the Contractor's fee by the sum of $100 for each day the Contractor delays completion of the work beyond the aforementioned date. If the payment has already been made, the Contractor shall reimburse to Client the sum of $100 for each day the Contractor delays completion of the work beyond the aforementioned date. The completion date may be adjusted for change orders or by mutual agreement signed in writing between the Contractor and the Client. 12. Warranty: The Contractor warrants the labor for one year after completion. If any item develops a problem within one year of completion, the Contractor shall repair it within seven (7) business days of being notified by the Client, at no additional expense to the Client. If the Contractor does not make the requested repairs within seven (7) business days, the Client may have a third party complete the repairs and the Client may charge the Contractor for all reasonable costs incurred to complete the repairs. 13. Waiver: Failure of the Client to insist upon strict compliance of any of the provisions of this Agreement shall not constitute a waiver of any violation, nor shall any partial payment outside of the "payment schedule" be deemed as a waiver of any of the Client's rights to strict compliance with any of the terms of this Agreement. 14. Address: The Contractor herewith provides to Client the true and correct residence address, home phone number, and Federal Employer Identification Number or Social Security Number. 15. Arbitration: The Client and Contractor agree that, if any controversy or claim arising out of or relating to this Agreement cannot be settled through direct discussions, they shall endeavor first to settle the controversy or claim by a mediation administered by JAMS under its applicable rules. IF THE CONTROVERSY OR CLAIM IS NOT OTHERWISE RESOLVED THROUGH DIRECT DISCUSSIONS OR MEDIATION, THE PARTIES AGREE THAT IT SHALL THEN BE RESOLVED BY FINAL AND BINDING ARBITRATION ADMINISTERED BY JAMS IN ACCORDANCE WITH ITS STREAMLINED ARBITRATION RULES AND PROCEDURES OR SUBSEQUENT VERSIONS THEREOF (THE "JAMS RULES"). THE JAMS RULES FOR SELECTION OF AN ARBITRATOR SHALL BE FOLLOWED, EXCEPT THAT THE ARBITRATOR SHALL BE AN ARBITRATOR LICENSED TO PRACTICE LAW IN FLORIDA OR A RETIRED JUDGE. ALL PROCEEDINGS BROUGHT PURSUANT TO THIS PARAGRAPH WILL BE CONDUCTED IN THE CITY OF MIAMI. THE PARTIES AGREE THAT THE REMEDY FOR ANY CLAIM BROUGHT PURSUANT TO THIS AGREEMENT SHALL BE LIMITED TO ACTUAL DAMAGES, AND IN NO EVENT SHALL ANY PARTY BE ENTITLED TO RECOVER PUNITIVE OR EXEMPLARY DAMAGES OR TO RESCIND THIS AGREEMENT OR SEEK INJUNCTIVE OR ANY OTHER EQUITABLE RELIEF. 16. Controlling Law: a. THIS AGREEMENT SHALL BE GOVERNED AND CONSTRUED IN ACCORDANCE WITH THE INTERNAL LAWS OF THE STATE OF FLORIDA APPLICABLE TO CONTRACTS ENTERED INTO AND FULLY TO BE PERFORMED THEREIN. TO THE EXTENT THE ARBITRATION PROVISIONS OF THIS AGREEMENT ARE NOT ENFORCED OR COURT PROCEEDINGS ARE OTHERWISE REQUIRED,COMMENCED OR MAINTAINED, THE PARTIES CONSENT AND AGREE TO THE EXCLUSIVE JURISDICTION AND VENUE OF THE STATE AND FEDERAL COURTS HAVING JURISDICTION OVER MIAMI-DADE COUNTY, FLORIDA, WITH RESPECT TO ANY ACTION THAT ANY PARTY DESIRES TO COMMENCE ARISING OUT OF OR IN CONNECTION WITH THIS AGREEMENT OR ANY BREACH OR ALLEGED BREACH OF ANY PROVISION OF THIS AGREEMENT, AND ALL PARTIES WAIVE ANY OBJECTION AS TO IMPROPER VENUE OR THAT ANY STATE OR FEDERAL COURT OF FLORIDA IS AN INCONVENIENT FORUM. b. Nothing in this Agreement shall be construed to require the commission of any act contrary to law, and in the event of any conflict between any provision of this Agreement and any present or future statute, law, ordinance or regulation, the latter shall prevail and the provision of this Agreement affected thereby shall be modified only to the extent necessary to bring it within legal requirements, such provision shall be deemed stricken and severed from this Agreement and the remaining terms of this Agreement shall continue in full force and effect. PROPERTY ACES, LLC 9740 SW 72"d Ave. Pinecrest FL, 33156 Phone: 786-878-4696; Email: infona,property-aces.com 17. Time is of the essence of this Agreement. 18. No Rule of Construction Against the Drafter. Any rule of construction to the effect that any ambiguity is to be resolved against the drafting parties shall not be applied to the interpretation of this Agreement. 19. Entire Agreement: The Agreement constitutes and represents the entire agreement between the Client and the Contractor, and supersedes and extinguishes all prior agreements, understandings, representations, warranties and arrangements of any nature, whether oral or written, between the parties relating to the work to be performed hereunder. The Agreement shall be binding upon and inure to the benefit of the parties and their respective successors and permitted assigns. The Agreement is not for the benefit of any other person, and no other person shall have any right under the Agreement against either party. 20. Special Stipulations: The following stipulations, if in conflict with any of the preceding, shall control: The Contractor and any/all sub -contractors rendering services on behalf of the contractor waives his/her right to hold the Client liable for any and all injuries occurring as a result of services rendered. IN WITNESS WHEREOF, all of the parties hereto affix their hands and seals. Clie Date: Contractor: Date: Social Sec r Federal ID g: j56 , Address: 2950 W 841h St. Unit 103 Hialeah, FL 33018 EXHIBIT "A" SERVICES PROVIDED - SCOPE OF WORK EXHIBIT "B" PAYMENT SCHEDULE EXHIBIT "C" INSURANCE AGREEMENT DOWNPAYMENT: No Down Payment Total cost for the services contained in this Agreement including labor and materials is: $30,200.00 ApACES PROPERTY ACES, LLC 9740 SW 72"d Ave. Pinecrest FL, 33156 Phone: 786-8784696; Email: info(¢,property-aces.com ga i+ r Certificate of Completion Miami Shores Village 10050 N.E. 2nd Ave, Miami Shores, Florida 33138 Tel: 305-795-2204 Fax: 305-756-8972 I Building Inspection Department j Description: REMODEL KITCHEN AND 2 BATHROOMS, FLOORING REPLACED RC-6-17-1685 06/15/2018 AS PER INSPECTOR ALEXIS RIVERON, THEY NEED TO MEET WITH THE BUILDING OFFICIAL. JOB HAS BEEN COMPLETED WITHOUT INSPECTIONS. Permit Type Building (Residential) Bldg. Permit No. RC-4-18-1122 1Owner PROPERTY ACES LLC Contractor VENUR CONSTRUCTION, LLC Subdivision/Project Date Issued 10/25/2018 I Construction Type V-B Occupancy R-3 Type y Square Footage 0.00 Flood Zone X Location If the building is located in a special flood hazard area documentation of the as -built lowest floor 240 NE 97 ST elevation or lowest horizontal structural member has been provided and is retained in the records of Miami Shores , FL 33138 Miami Shores Village. This certificate issued pursuant to the requirements of the Florida Building Code certifying that at the MORES time of issuance this structure was in compliance with the various ordi ances of the jurisdictionNC.•av, V P • 1<< regulating building construction or use. lul Building Officials Approval Ismael Naranjo, CBO t% v Miami Shores Village Permit NO. RC-4-18-1122 Permit Type: 10050 N.E. 2nd Avenue Work Classificallion: ami ores, Phone: (305)795-2204 Fax: (305)756-8972FCORtDAissueDate: 511/2018 INSPECTION REQUESTS: (305)762-4949 or Log on at https://bldg.miamishoresvillage.com/cap REQUESTS ARE ACCEPTED DURING 8:30AM - 3:30PM FOR THE FOLLOWING BUSINESS DAY. Requests must be received by 3 pm for following day inspections. Expires: 10/2812018 Residential Construction Parcel #A 132060134020 Owner's Name: Owner's Phone: Job Address: 240 NE 97 Street Total Square Feet: 0 Miami Shores FL 33138- tioTotalJobValuation: $70,000.00 Bond Number: Contractor(s) Phone i Primary Contractor VENUR CONSTRUCTION, LLC (305)903-1795 Yes WORK IS ALLOWED: MONDAY THROUGH FRIDAY, 8:OOAM - 7: SATURDAY 8:OOAM - 6:00PM. NO WORK IS ALLOWED ON SUNDAY OR BUILDING AND ROOFING INSPECTIONS ARE DONE MONDAY THROUGH FRIDAY. j k1,4ezz*1r V" 0- A- 0 NO IAPECTION ILL BE MADE UNLESS THE PERMIT CARD IS DISPLAYED AND HAS BEEN APPROVED- PLANS ARE READLY AVAILABLE. IT IS THE PERMIT APP CANT'S RESPONSIBILITY TO ENSURE THAT WORK IS ACCESSIBLE AND EXPOSED FOR INSPECTION PURPOSES NEITHER THE BUILDING OF ICIAL NOR THE CITY SHALL BE LIABLE FOR EXPENSE ENTAILED IN THE REMOVAL OR REPLACEMENT OF ANY MATERIAL REQUIRED TO ALLOW INSPECTION. WARNING TO OWNER: YOUR FAILURE TO RECORD A NOTICE OF COMMENCEMENT MAY RESULT IN YOUR PAYING TWICE FOR IMPROVEMENTS TO YOUR PROPERTY. A NOTICE OF COMMENCEMENT MUST BE RECORDED AND POSTED ON THE JOB SITE BEFORE THE FIRST INSPECTION. IF YOU INTEND TO OBTAIN FINANCING, CONSULT WITH YOUR LENDER OR AN ATTORNEY BEFORE COMMENCING WORK OR RECORDING YOUR NOTICE OF COMMENCEMENT. fur INSPECTION DATE INSP L, Foundation Stemwall Slab Columns (1st Lift) Columns (2nd Lift) Tie Beam Truss/Rafters Roof Sheathing Bucks Interior Framing Insulation Ceiling Grid Drywall Firewall Wire Lath Pool Steel Pool Deck Final Pool Final Fence Screen Enclosure Driveway Driveway Base Tin Cap Roof in Progress Mop in Progress Final Roof Shutters Attachment M —1 C h uaJIIUILCI J Rails and Guardrails ADA compliance DOCUMENTS Soil Bearing Cert Soil Treatment DOCUMENTS Flour Elevations Survey Reinf Unit Mas Cert Ilnci lotinn ('orFifirotc. Spot Survey Final Survey Truss Certification STRUCTURAL COMMENTS WINDOWS& DOORS INSPECTION D . E INSP Attachment 1 PUBLIC INSPECTION WORKS DATE INSP Excavation 6— mm— INSPECTION W14GI DATE INSP Temporary Pole 30 Day Temporary Pool Bonding Pool Deck Bonding Pool Wet Niche Underground Footer Ground Slab Wail Rough Ceiling Rough Rough Telephone Rough Telephone Final TV Rough TV Final Cable Rough Cable Final Intercom Rough Intercom Final Alarm Rough Alarm Final Fire Alarm Rough Fire Alarm Final Service Work With 4 .. G' ELECTRICAL COMMENTS i I INSPECTION DATE INSP Rough Water Service 2nd Rough r l Top Out F Fire Sprinklers Septic Tank Sewer Hook-up Roof Drains Gas LP Tank Well Lawn Sprinklers Main Drain Pool Piping Backflow Preventor Interceptor Catch Basins Condensate Drains HRS Final PLUMBING COMMENTS J MECHANICAL INSPECTION DATE INSP Underground Pipe Rough Ventilation Rough Hood Rough IPressureTest 1 1 Final Hood Final Ventilation Final Pool Heater Final Vacuum MECHANICAL COMMENTS v If P i-