Loading...
RC-18-1285Miami Shores Village 10050 N.E. 2nd Avenue NE Miami Shores, FL 33138-0000 Phone: (305)795-2204 Project Address Permit Permit N©. RC-5-18-1285 Permit Type: Residential Construction Work Classification: Solar PermitStatus: APPROVED Issue Date: 6/11/2018 Expiration: 12/08/2018 Parcel Number Applicant 296 NE 99 Street Miami Shores, FL 33138 1132060134300 Block: Lot: JEFF KAMP BARBARA KAMP Owner Information Address 296 NE 99 Street MIAMI SHORES FL 33138- 296 NE 99 Street MIAMI SHORES FL 33138- f Contractor(s) GOLDIN SOLAR, LLC Phone (305)469-9790 Cell Phone Phone Cell Valuation: Total Sq Feet: $ 12,700.00 0 Approved: In Review Comments: Date Approved: : In Review Date Denied: Type of Construction: GRID TIRED SOLAR PV Stories: Front Setback: Left Setback: Bedrooms: Plans Submitted: Yes Certificate Date: Bond Return : Occupancy: Single Family Exterior: Rear Setback: Right Setback: Bathrooms: I Certificate Statu1s: Additional Info: GRID TIRED SOLAR PV Classification: Residential Fees Due CCF DBPR Fee DCA Fee Education Surcharge P&Z Review Fee Permit Fee Plan Review Fee (Engineer) Scanning Fee Technology Fee Total: Amount $7.80 $5.72 $3.81 $0.00 $0.00 $0.00 $0.00 $0.00 $0.00 $17.33 Pay Date Pay Type Invoice # RC-5-18-67536 06/11/2018 Credit Card Amt Paid Amt Due $ 17.33 $ 0.00 Available Inspections: Inspection Type: Final Solar Review Electrical Review Building Review Structural In consideration of the issuance to me of this permit, I agree to perform the work covered hereunder in compliance with all ordinances and regulations pertaining thereto and in strict conformity with the plans, drawings, statements or specifications submitted to the proper authorities of Miami Shores Village. In accepting this permit I assume responsibility for all work done by either myself, my agent, servants, or employes. I understand that separate permits are required for ELECTRICAL, PLUMBING, MECHANICAL, WINDOWS, DOORS, ROOFING and SWIMMING POOL work. OWNERS A constr VI . . ertify that all the foregoing information is accurate and that all work will be done in compliance with all applicable laws regulating therm9re,J ove-named contractor to do the work stated. ��tJionz 1, fie a orized Signature: Owner / Applicant Contractor / Agent June 11, 2018 Date Building Department Copy June 11, 2018 1 BUILDING PERMIT APPLICATION BUILDING ❑ ELECTRIC 0PLUMBING 0 MECHANICAL JOB ADDRESS: 296 NE 99th Street Miami Shores Village Building Department 10050 N.E.2nd Avenue, Miami Shores, Florida 33138 Tel: (305) 795-2204 Fax: (305) 756-8972 INSPECTION LINE PHONE NUMBER: (305) 762-4949 0 ROOFING PUBLIC WORKS RECEIVED MAY152018 `L1 CC h FBC2014- V� Master Permit No. 18 ' I Z9S Sub Permit No. 0 REVISION 0 EXTENSION 0 RENEWAL 0 CHANGE OF 0 CANCELLATION 0 SHOP P CONTRACTOR DRAWINGS City: Miami Shores Folio/Parcel#: 11-3206-013-4300 County: FL Miami Dade Zip: 33138 i Is the Building Historically Designated: Yes NO Occupancy Type: Load: Construction Type: Flood Zone: OWNER: Name (Fee Simple Titleholder): Barbara and Jeff Kamp Address 296 NE 99th Street BFE: FFE: Phone#: (305) 389-5194 City Miami Shores State: Fl Zip: 33138 Tenant/Lessee Name: Phone#: (786) 257-5345 Email: Barbara@friedberg.org/ Jayarek@gmail.com CONTRACTOR: Company Name: Goldin Solar LLC Address: 3447 percival ave Phone#: 305-469-9790 City: Miami State: Florida Zip: 33133 Qualifier Name: Daren Goldin 305-469-9790 Phone#: State Certification or Registration #: CVC56965 Certificate of Competency #: DESIGNER: Architect/Engineer: Phone#: Address: City: State: Zip: Value of Work for this Permit: $ I Z 700 , Square/Linear Footage of Work: Type of Work: ❑ Addition ❑ Alteration X New ❑ Repair/Replace ❑ Demolition Description of Work: Grid Tied Solar PV Specify color of color thru tile: Submittal Fee $ Permit Fee $ CCF $ CO/CC $ Scanning Fee $ Radon Fee $ DBPR $ Technology Fee $ Training/Education Fee $ Structural Reviews $ (Revised02/24/2014) Notary $ Double Fee $ Bond $ TOTAL FEE NOW DUE $ 1 33 me or who has produced ' Bonding Company's Name (if applicable) Bonding Company's Address City State Zip Mortgage Lender's Name (if applicable) Mortgage Lender's Address City State Zip Application is hereby made to obtain a permit to do the work and installations as indicated. I certify that no work or installation has commenced prior to the issuance of a permit and that all work will be performed to meet the standards of all laws regulating construction in this jurisdiction. I understand that a separate permit must be secured for ELECTRIC, PLUMBING, SIGNS, POOLS, FURNACES, BOILERS, HEATERS, TANKS, AIR CONDITIONERS, ETC OWNER'S AFFIDAVIT: I certify that all the foregoing information is accurate and that all work will be done in compliance with all applicable laws regulating construction and zoning. "WARNING TO OWNER: YOUR FAILURE TO RECORD A NOTICE OF COMMENCEMENT MAY RESULT IN YOUR PAYING TWICE FOR IMPROVEMENTS TO YOUR PROPERTY. IF YOU INTEND TO OBTAIN FINANCING, CONSULT WITH YOUR LENDER OR AN ATTORNEY BEFORE RECORDING YOUR NOTICE OF COMMENCEMENT." Notice to Applicant: As a condition to the issuance of a building permit with an estimated value exceeding $2500, the applicant must promise in good faith that a copy of the notice of commencement and construction lien law brochure will be delivered to the person whose property is subject to attachment. Also, a certified copy of the recorded notice of commencement must be posted at the job site for the first inspection which occurs seven (7) days after the building permit is issued. In the absence of such posted notice, the inspection will not be approved and a reinspection fee will be charged. The foregoing instrument was acknowledged before me this 7 Qday of Lta1/1 , 20 \ 0 by kanip , who is personally known to 'FL OL identification and who did take an oath. NOTARY PUBLIC: Sign: Print: Seal: el ►% Notary Public State of Florida Madelin Rojas , c' My Commission GG 157509 OFa Expires 11/05/ '21 Signature CONTRACTOR The foring instrument was acknowledged before me this day o �I-�QJ�(° i , 20 t g , by (ei1 6ICGI , who is ersonally known to as me or who has produced identification and who did take an oath. NOTARY PUBLIC: Sign: Print: Seal: as ►U,` Notary Public State of Florio. Madelin Rojas o My Commission GG 157'; oa` Expires •?oiB ************************************************************************* APPROVED BY r Plans Examiner Zoning 917/11 Structural Review Clerk (Revised02/24/2014) orIo/ZU1a property Search Application - Miami -Dade County Summary Report Property Information Folio: 11-3206-013-4300 Property Address: 296 NE 99 ST Miami Shores, FL 33138-2435 Owner JEFF KAMP BARBARA KAMP Mailing Address 296 NE 99 ST MIAMI, FL 33138 USA PA Primary Zone 1000 SGL FAMILY - 2101-2300 SQ Primary Land Use 0101 RESIDENTIAL - SINGLE FAMILY: 1 UNIT Beds / Baths / Half 3/3/0 Floors 1 , Living Units 1 Actual Area Sq.Ft Living Area Sq.Ft Adjusted Area 2,481 Sq.Ft i Lot Size 8,998.75 Sq.Ft Year Built 1941 Assessment Information Year 2017 2016 2015 Land Value $270,070 $225,059 $216,204 Building Value $118,518 $118,872 $119,227 XF Value $0 $0 $0 Market Value $388,588 $343,931 $335,431 Assessed Value $299,082 $292,931 $290,895 Benefits Information Benefit Type 2017 2016 2015 Save Our Homes Cap Assessment Reduction $89,506 $51,000 $44,536 Homestead Exemption $25,000 $25,000 $25,000 Second Homestead Exemption $25,000 $25,000 $25,000 Note: Not all benefits are applicable to all Taxable Values (i.e. County, School Board, City, Regional). • Short Legal Description MIAMI SHORES SEC 1 AMD PB 10-70 LOT 1 & E1/2 LOT 2 BLK 32 LOT SIZE 78.250 X 115 COC 24308-0511 02 2006 1 Generated On : 5/15/2018 Taxable Value Information 2017 2016 2015 County Exemption Value $50,000 $50,000 $50,000 Taxable Value $249,082 $242,931 $240,895 School Board Exemption Value $25,000 $25,000 $25,000 Taxable Value $274,082 $267,931 $265,895 City Exemption Value $50,000 $50,000 $50,000 Taxable Value $249,082 $242,931 $240,895 Regional Exemption Value $50,000 $50,000 $50,000 Taxable Value $249,082 $242,931 $240,895 Sales Information Previous Sale Price OR Book -Page Qualification Description 06/25/2012 $300,000 28167-0087 Qual by exam of deed 02/01/2006 $555,000 24308-0511 Sales which are qualified 02/01/1995 $125,000 16699-0814 Sales which are qualified The Office of the Property Appraiser is continually editing and updating the tax roll. This website may not reflect the most current information on record. The Property Appraiser and Miami -Dade County assumes no liability, see full disclaimer and User Agreement at http://www.miamidade.gov/info/disclaimer.asp Version: P t1--0 70 14M A -, GOLDIN SOLAR PHOTOVOLTAIC (SOLAR) INSTALLATION AGREEMENT (Co -Op Version — North Miami Dade) )3 CrQX THIS "AGREEMENT" made this day of onth March . Year 2018_, by and between Goldin Solar, LLC, Florida State license no. CV 965 hereinafter referred to as "CONTRACTOR", and between Owner Name; _Barbara and Jeff Kamp hereinafter referred to as "OWNER". WITNESSETH, that the Contractor and the Owner for the consideration named agree as follows: ((Agreement Date will be the date when Goldin Solar receives 5% payment). ARTICLE 1. SCOPEOF THE WORK The Contractor shall furnish all the labor and materials to perform all of the work shown on the described specifications and plans which are referenced and incorporated herein to install a Photovoltaic System otherwise described in this ARTICLE 1 (hereinafter the "Work"), on property located at (hereinafter "Property"): 296 NE 99th Street Miami Shores, FL. 33138 1. Design, procure and install a 35_ panels, Brand Hanwha Q-Cells Duo (315)_ W/Panel) modules ( 11,025_Total Watts Win total) grid -tied photovoltaic system, utilizing SolarEdgeinverter(s) (Model 10000) and _35 SolarEdge DC power optimizers. If the specified panels become unavailable in the South Florida market at a commercially reasonable price, Goldin Solar reserves the right to substitute the panels to provide required total kW of power as outlined in this contract. Tree removal/trimming/relocation not included. 2. The number of PV modules and power capacity in kW as described in provision 1 of Article 1 above is based on the initial site visit. If during the detailed engineering and design phase or permitting with the local building department it is found that fewer modules can fit on the premise than originally planned, the Owner will be credited in the form of a deductive change order, deducting from payment 2 as outlined in Article 4 (or from total if financed), in the appropriate dollars per watt amount that this contract Is based on ( $2.30 $/W for fiat and $2.50/watt for tile). One panel to be installed on tile roof due to space limitations o $787.50 or $63 additional for one panel. ARTICLE 2. TIME OF COMPLETION flat roof. See Helioscope Report. $2.50/watt * 315 watts = The work to be performed under this Contract shall be commenced after a) contract signature by Owner, and b) receipt of the initial payment by Owner. The Work shall be substantially completed usually within 12-16 weeks from the commencement date. The completion date may vary due to project conditions, changes in the work, weather, material availability, force majeure, etc. Owner agrees that Contractor shall not be liable for any form of delay damages based upon Contractor caused delay or delay caused by others and any such delay damages are waived and released by Owner against Contractor. ARTICLE 3. CONTRACT PRICE The Owner shall pay the Contractor for the work to be performed under the terms of the Contract the sum of $ (_315 W * 34 * $2.30/W = $24,633 AND 315 W * 1 * 2.50W = 787.50 TOTAL = $25,420.50 Dollars) subject to additions and deductions pursuant to authorized change orders. ARTICLE 4. PROGRESS PAYMENTS This project will be financed by: NA and is subject to: NA terms. Owner initials: K Contractor initials: D 6 ) Page 1 of 13 GOLDIN SOLAR Final payment will be due after completion of on -site installation of the solar modules, inverters and obtaining final approval for permit inspection from the authority having jurisdiction (hereinafter "AHJ") over for the Project. Interconnection with utility company may take several weeks after installation of system. The Owner understands that final payment will not be withheld by any person or entity due to utility interconnection. It is the sole responsibility of Owner to fulfil its obligations to financing company. Owner is obligated to ensure payment to Contractor irrespective of Owner's account standing with its financing company. The Owner is exclusively responsible for timely making all payments due hereunder to Contractor. Time is of the essence regarding all payment obligations of the Owner. Payment Milestones (Consistent with Co -Op Agreement) a 5% - At Contract Signing = $1,271.03 45% - Upon Issuance of Building Permit = S11,439.23 50% - At final inspection =12,710.24 ARTICLE 5. GENERAL PROVISIONS Plans/Permitting/Licensing 1. All work shall be completed in a workman like manner and in compliance with all building codes and other applicable laws as governed by the local AHJ (Authority Having Jurisdiction). 2. To the extent required by law, all work shall be performed by individuals duly licensed and authorized by law to perform said work. Goldin Solar, LLC is a licensed solar contractor: Florida license #CVC56965 3. Contractor, may at its discretion, engage subcontractors and others to perform work hereunder, provided contractor shall fully pay said subcontractor and In all instances remain responsible for the proper completion of this contract. 4. Contractor shall at its own expense obtain all permits necessary for the Work to be performed under this Contract. In the event that existing portions of the building are inconsistent with the records of the AHJ and the AHJ requires reconciliation of existing building documentation, contractor will not be liable for reconciliation of existing building documentation with AHJ. Moreover, Owner shall be responsible for any and all code upgrades or modifications and all costs related thereto, regarding its existing property, including but not limited to, the roof or electrical system should any such upgrades be required by the AHJ. 5. CONTRACTOR will obtain and pay for all required building permits and OWNER will pay assessments and charges required by public bodies and utilities for financing or repaying the cost of sewers, storm drains, water service, and other utilities including charges for sewer and storm drain reimbursement, revolving funds, hookup, and other similar charges. Unless otherwise specified, work does not include any changes or alterations from the drawings or specifications that may be required by any public body, utility, or inspector. CONTRACTOR, at CONTRACTOR's option, may alter specifications only so as to comply with requirements of governmental agencies having jurisdiction over same. The cost of any alteration undertaken to comply with any such requirements shall be in addition to the Contract price specified herein. Additional work/Contract Modification 6. If Owner, Construction Lender, or any public body or inspector directs any modification or addition to the work covered by this Contract, the charge for that extra work shall be determined in advance and the cost shall be added to the Contract price in addition to CONTRACTOR's usual fee for overhead and profit. OWNER shall make payments for all extra work as that work progresses, concurrently with regularly scheduled payments. CONTRACTOR shall do no extra work without the prior written authorization of the OWNER. Any authorization for extra work shall show the agreed terms and shall be approved and signed by both parties. 7. Unless specifically included in this Contract, electrical work shall not involve a change to any existing service panel other than the addition of circuit breakers or fuse blocks to distribute electric current to new outlets. This Contract Page 2 of 13 Owner initials: P(� Contractor initials: t & GOLDIN SOLAR does not include changes to existing wiring in areas undisturbed by alterations. All existing electrical wiring systems are assumed to be, and OWNER represents them to be, adequate to carry the load imposed by existing work. Any work necessary to correct these existing conditions shall be an extra work Item subject to Paragraph 6 of this Contract. 8. There shall be a reasonable allowance on all dimensions specified in work plans. All sizes are outside approximate sizes. If there is any conflict between sketches, renderings, views, pictures, plans, blueprints, etc., and the terms of this Contract, then this Contract shall be controlling. CONTRACTOR is not responsible for any existing illegal conditions. CONTRACTOR is not responsible for any unusual or abnormal concrete footings, foundations, retaining walls, or piers required, or any unusual depth requirements, such as, but not limited to, conditions caused by poor soil, lack of compaction, hillside, or other slope conditions. CONTRACTOR may, but is not obligated to, correct those conditions. All work necessary to correct abnormal conditions that is required by public bodies shall constitute an extra work item and the cost shall be in addition to the Contract price specified herein. Insurance and Liabilities 9. Contractor is presently insured under the following types of insurance policies: 1) commercial general liability; 2) workers compensation, and 3) automotive liability. 10. The liability of the Contractor shall be limited to the area of installation for the photovoltaic system as outlined by the plans permitted by the AHJ. a. Contractor shall also not be liable for the present condition of or existing damage to the existing property, including but not limited to old, deteriorated or improperly installed sub -roofing, roof covering or supports, siding, exterior covering/painting. b. Contractor's aggregate monetary liability shall be limited to amounts paid by the Owner to Contractor under this agreement. Any claims or alleged damages above and beyond said contract price are hereby waived and released by Owner. c. Contractor specifically disclaims and disavows any alleged claims or representations of any guaranteed output of the Installed system, including any claims made orally or in writing by the Contractor or its employees or agents. This Agreement, along with any exhibits, schedules, and amendments hereto, encompasses the entire agreement of the parties, and supersedes all previous understandings and agreements between the parties, whether oral or written. The parties hereby acknowledge and represent, that they have not relied on any representation, assertion, guarantee, warranty, collateral contract or other assurance, except those set out in this Agreement, made by or on behalf of any other party or any other person or entity whatsoever, prior to the execution of this Agreement. The parties hereby waive all rights and remedies, at law or in equity, arising or which may arise as the result of a party's reliance on such representation, assertion, guarantee, warranty, collateral contract or other assurance. d. The Owner waives all claims against Contractor for all consequential damages arising out of or relating to this Contract. This waiver includes but is not limited to: damages incurred by the Owner for rental expenses, for losses of use, income, profit, financing, business and reputation, and for loss of management or employee productivity or of the services of such persons. e. Contractor has at the time of site visit informed Owner,that area proposed for solar is subject to partial shading, and some tree trimming (not performed by Contractor) will be required for maximum output performance. f. Contractor will not be liable for any default, delay or failure in the performance under this contract due to Force Majeure. Force Majeure cannot be attributable to fault or negligence on the part of the party claiming Force Majeure and must be caused by things beyond parties reasonable control. Use of Premise 11. OWNER shall grant free access to work areas for workers and vehicles and shall provide areas for storage of materials and debris. OWNER agrees to keep driveways clear and available for movement and parking of trucks during scheduled working hours. OWNER shall be responsible for securing all entrances to the jobsite In a manner adequate Page 3 of 13 Owner initials: Contractor initials: GOLDIN SOLAR to prevent persons other than OWNER, CONTRACTOR, and any authorized workers or material suppliers from gaining access to that site. CONTRACTOR shall be responsible, at the end of every workday, for storing all equipment and materials in the facilities provided by Owner. KM 3/9/18 CONTRACTOR shall keep Owner advised as to the hours during which work is. scheduled to be performed at the jobsite. If Owner denies access to any worker or supplier of materials during scheduled working hours, then Owner will be deemed in breach of this Contract and subject to liability for any damages caused by the breach. 12. During the term of this Agreement, Goldin Solar may erect one temporary sign showing its name, service mark, trade name or other commercial name, identifying Goldin Solar as performing services on the construction project. The sign must be appropriate in appearance, style and size, and must conform to all applicable federal, state and local laws. 13. Contractor agrees to remove all debris and leave the premises in broom clean condition upon project completion. 14. The Owner represents and warrants to the Contractor the following: a. Owner represents and warrants that its property complies with the current Florida Building Code, all prior permits for work at the Property have been inspected, approved, and closed out and there are no existing permit violations regarding the Property. The Owner further represents and warrants that no unpermitted work has taken place at the Property. b. Owner represents and warrants that there are no existing roof leaks and the roof is in adequate condition to receive the Work hereunder. c. Owner represents that there is no termite damage or structural problems with the Property that may prevent the installation or operation of the Work hereunder. d. The Owner represents and warrants that there shall be no other contractors workin at the job site who may interfere with Contractor's work or schedule; and Owner will not execute an additional contract with a different solar contractor after hiring Goldin Solar during the life of the project except upon property termination of this Contract by either party as otherwise described herein. The Owner shall hold harmless, indemnify and defend Contractor from any violation or breach of the above referenced representations and warranties. The Owner shall further pay Contractor any damages incurred by or hon behalf of the Contractor for breach of the above referenced representations and warranties. Additional Time/Work Stoppage 15. CONTRACTOR shall start and diligently pursue work through to completion, and shall not be responsible for delay damages. The following delays, among others, shall entitle contractor to a time extension and potential damages, failure of the issuance of all necessary building permits within a reasonable length of time; funding of loans; disbursement.of funds into funding control or escrow; acts of neglect or omission by OWNER or OWNER's employees or agents; acts of God; stormy or inclement weather; strikes, lockouts, boycotts, or other labor union activities; extra work ordered by OWNER; acts of public enemy; riots or civil commotion, inability to secure material through regular recognized channels; imposition of Government priority or allocation of materials; OWNER's failure to make payments when due; delays caused by inspection or changes ordered by the inspectors of authorized governmental bodies; acts of independent CONTRACTORs; holidays; or any other circumstances beyond CONTRACTOR's control. Under no circumstances shall Contractor be responsible for delay damages. Contractor may at any time and for any reason terminate this Contract and all services and Work hereunder at Contractor's convenience after written notice to Owner. Upon receipt of the written notice of termination for convenience notice, Contractor shall immediately discontinue the work and placing of orders for materials, facilities and supplies in connection with the performance of this Contract. If Contractor serves said written notice of termination for convenience to Owner, Owner shall be entitled to pick up any materials purchased by Contractor on its behalf and plans designed for its Project which have been received by Contractor prior to the service of the Notice for Termination for Convenience. Owner shall be entitled to no consequential or incidental damages hereunder. No Page 4 of 13 Owner initials: Contractor initials: GOLDiN SOLAR refund shall be provided to Owner. Contractor shall specifically not be liable for any damages or greater cost to complete with another contractor. 16. CONTRACTOR shall have the right to stop work and keep the job idle if payments are not made to CONTRACTOR when due. Time is of the essence regarding all payment obligations by Owner. If the work is stopped, for any reason, for a period of 60 days, then CONTRACTOR may, at CONTRACTOR's option, on five days written notice, demand and receive payment for all work executed and materials ordered or supplied and any other loss sustained, including CONTRACTOR's normal overhead plus a profit of 10 percent of the Contract price. Thereafter, CONTRACTOR is relieved from any further liability. If work stops for any reason, OWNER shall provide for protection of all material on the premises and shall be responsible for any damage, warpage, racking, or loss of that material. Payment Policy/Arbitration 17. Payments are due as outlined in Article 4 of this agreement. In the event that Owner shall fail to pay any periodic or installment payment due hereunder, Owner will be considered in default and/or Contractor may cease work. In this event Owner would be considered in breach of contract pending payment or resolution of any dispute. A rate of 1.5% interest per month or maximum allowable by law, whichever Is greater will be assessed to the outstanding balance. In the event contractor engages an attorney for collection of past due amount, Owner shall be liable for all reasonable attorney fees. If any payment remains unpaid for a period of 120 days, Owner grants to contractor the right to enter the property and remove the system or any part thereof. Contractor will provide 15 day written notice of Its intent to remove the system and allow this time for Owner to cure the defect. All disputes arising out of or relating to this agreement, breach of agreement or contract work hereunder shall be resolved by binding arbitration in accordance with' the rules of the American Arbitration Association under construction industry arbitration rules. The parties recognize and agree that by agreeing to this provision, they are waiving any right they may have to a jury trial. Judgment on the arbitration award may be entered in any court having jurisdiction thereof. In the event of any arbitration or litigation arising from this contract, the prevailing party shall be entitled to recover from the non -prevailing party, its costs and reasonable attorneys' fees. 18. Early contract termination: The Owner has the right to terminate this agreement without incurring any cost or consequence within (3) business days of singing this agreement — see last page of this agreement. Should the Owner elect to terminate this agreement after the aforementioned (3) business day "right to cancel" and prior to the contract fulfilment/payment early contract termination will take place as follows: Owner will notify Contractor in writing of his or her intention to terminate the agreement. Contractor will reply in writing to Owner confirming that the Owner's Intent to terminate has been received and will note the project stage at the time the request to terminate was received. Upon early termination, Owner will be liable to pay Contractor for work performed up to accepted termination date. The termination date will be considered the date that Contractor has replied to Owner acknowledging their intent to terminate. The Owner's financial liability to contractor resulting from early termination will be in accordance with the following table: Project Phase of Early Termination Financial Liability of Owner to Contractor 1. Prior to performance of site survey $1,000 administrative fee + acquisition cost (20% of contract value).. ... . 2. After site survey has taken place, prior to commencement of detailed engineering I $1,500 administrative fee + site survey fee + acquisition cost (20% of contract value) 3. After site survey and detailed engineering have taken place, prior to submission of plans to building department for permitting $3,000 administrative fee + site survey fee + detailed engineering fee + acquisition cost (20% of contract Page 5 of 13 Owner initials: Contractor initials: PG. - GOLDIN SOLAR value) 4. After site survey and detailed engineering have taken place and plans have been submitted to permitting Note: if Owner cancels at this phase, they will be entitled to the materials purchased for them for this project, but will be required to pick up said materials from Goldin Solar, Central FL location $5,000 administrative fee +, site survey fee + detailed engineering + permitting + project material value + acquisition cost (20% of contract value) After construction has commenced, contract cancelation will not be accepted and Contractor will fulfil its obligations to complete work and close out permit subject to the terms and conditions herein. Owner will grant Contractor free and clear access to the property to allow Contractor to complete construction. Should Owner elect to terminate the agreement early as outlined in steps 1-5 above, Contractor will send Owner invoice for expenses incurred per the above table. Owner will have (10) calendar days to issue payment to Contractor upon invoicing, and this payment will be due in full regardless of any financing intentions. If payment is not received in (10) calendar days, a rate of 1.5% interest per month or maximum allowable by law, whichever is greater will be assessed to the outstanding balance. 19. Failure to respond in a reasonable time to requests for information or unreasonable delays on part of Owner, determined at the sole discretion of Contractor, will be deemed to constitute early contract termination. Once contractor has received a permit from building department, Contractor will notify Owner that the permit has been received and will schedule a date to commencement construction work. .Owner may delay said construction commencement date a maximum of (30) calendar days from the original commencement date requested by contractor. If Owner either delays commencement date by more than (30) calendar days or does not respond to contractor's requests to schedule commencement, the contract will be deemed in default and subject to the cancelation terms outlined in article 18 above. In particular, if owner does not permit construction commencement within (30) days of permit issuance and notification by contractor, early project termination phase number 4 above will be deemed, without the service of any written notices If the Owner schedules a delivery date with Contractor, and the materials cannot be delivered on said date due the Owner's availability or by a failure caused by the Owner, and the Owner fails to reschedule a delivery date in advance of the prior date, a redelivery fee of $500 will be assessed by Contractor against Owner. Corrective or Repair Work 20. If minor items of corrective or repair work remain to be accomplished by CONTRACTOR after the project is ready for occupancy, CONTRACTOR shall perform the work expeditiously and OWNER shall not withhold any payment pending completion of that work. If 'major items of corrective or repair work remain to be accomplished after the building is ready for occupancy, and the aggregate cost of that work exceeds one percent of the gross Contract price, then OWNER, pending completion of the work, may withhold payment of a sufficient amount to pay for completion of the work, but shall not withhold any greater amount. Warranty 21. Contractor warrants the installation of the system against defects in workmanship for a period of Eleven (11) year following the conclusion of installation, starting on the day that the AHJ grants the final inspection approval. The warranty covers workmanship of the PV system. This warranty does not cover force majeure, damage caused by others which shall include but not be limited to, falling trees or branches, power outages, or normal wear and tear or the roof, roof shingle failure, sub -structure failure, siding or electrical system failure. The warranty does not cover damage caused by animals or by improper maintenance of the structure or the system or by any action of parties other than the Contractor. In the event the Owner discovers a defect within the warranty period, Owner shall notify Contractor in writing describing the nature and extent of the defect. Contractor will correct the defect covered by the warranty and repair the system at no additional cost to the Owner. If a part repair or replacement is required, Owner Page 6 of 13 Owner initials: Contractor. initials: 17 6- GOLDIN SOLAR shall cooperate fully with Contractor for a safe and efficient repair. Contractor makes no express or implied warranty, except as expressly outlined in this contract. Installed PV system parts (PV modules and the inverter) have their own manufacturer warranty for a period greater than the warranty specified under this provision. In the event that PV modules or the inverter require repair or replacement beyond the Contractor's warranty, but within the material manufacturer's warranty, the Contractor will support the Owner in the process of repair or replacement of the manufacturer warranted materials, however an appropriate labor cost will be assessed. No Consequential Damages & Limitation of Liability 22. Goldin Solar's liability to you under this agreement shall be limited to direct, actual damages only. You agree that in no event shall Goldin Solar shall be liable for any consequential, incidental, punitive, exemplary, special or indirect damages. Indemnity 23. To the fullest extent permitted by law, you shall indemnify, defend, protect, save and hold harmless Goldin Solar, its employees, officers, directors, agents, successors and assigns from any and all claims and third party claims, actions, cost, expenses (including reasonable attorneys' fees and expenses), damages, liabilities, penalties, losses, obligations, Injuries, demands and liens of any kind of nature arising out of, connected with, relating to or resulting from your negligence or willful misconduct; provided, that nothing herein shall require you to indemnify Goldin Solar from its own gross negligence or willful misconduct. The provisions of this Paragraph shall survive termination or expiration of this Lease. This indemnity shall be limited in amount to $250,000.00, which the parties agree is a commercially reasonable amount. This provision shall be deemed to be included with In the parties "bid documents." Severability 24. The provisions of this Agreement. shall be severable in the event that any of the provisions hereof (including any provision within a single section, paragraph or sentence) are held by a court of competent Jurisdiction, or arbitrator, to be invalid, void or otherwise unenforceable, and the remaining provisions shall remain enforceable to the fullest extent permitted by law. Furthermore, to the fullest extent possible, the provisions of this Agreement (including, without limitations, each portion of this Agreement containing any provision held to be invalid, void or otherwise unenforceable, that is not itself invalid, void or unenforceable) shall be construed so as to give effect to the intent manifested by the provision held invalid, illegal or unenforceable. Notice 25. Any notice required or permitted under this Contract, may be given by ordinary or electronic mail at the addresses specified in this Contract. If either party changes his or her address, that party shall provide written notice of the change to the other party. Notice shall be considered received one day after it is deposited in the mail with postage prepaid. Contract Integration Clause 26. This document and all documents Incorporated by reference constitute the parties' entire Contract. No other Contracts, oral or written, regarding the work to be performed under this Contract exist between the parties. This Contract shall be construed in accordance with, and governed by, the laws of the State of Florida. 23. The system inverter can be connected to the Internet to allow for monitoring of energy production. Internet connectivity will be provided with wireless kit to connect Inverter to wireless Internet. Wireless communication kit — Included 24. OPTIONAL SYSTEM MAINTENANCE AND MONITORING: Goldin Solar offers a monitoring and maintenance plan, which includes periodic monitoring of system performance via the Internet, and an annual system Inspection, maintenance and preparation of a report for the Owner outlining system performance relative to the predicted performance. The maintenance plan cost is $ .00 per year. Page 7 of 13 Owner initials: Contractor_ initials: p GOLDIN SOLAR Number of years desired maintenance plan: i ' Maintenance plan cost added: !� Optional Solar Attic fan: Watts: i Price: Initial: WI 25. Contractor will cause a licensed design professional to prepare engineering and design as required by AHJ to commence construction in compliance with all appropriate codes as otherwise required for the Work hereunder and as specified herein If additional structural support is needed as determined by structural engineer, with an associated cost, Contractor will obtain a change order from the Owner for the additional amount. 26. Contractor will call for final inspection as required by AHJ. At the time that the final inspection is passed, final payment (payment 3) is due. Technical Disclosures 27. There is great deal of information to understand about solar energy science, technology, power production and rules, and policies that govern solar locally before deciding to go solar. We feel that there are a few items in particular that are critical to understand. Please initial next to each of the following to indicate that you have been informed about said item and attained understanding of it. By initialing each item, you acknowledge that you have had sufficient opportunity to ask and learn about these items. Initial: Initial: a. Unless explicitly stated in this agreement, the type of solar system that Is being contracted is known as a "grid -tied" solar system. This means that battery backup is not included, but may be added on a future date. Grid -tied solar systems will receive a net -meter from the local utility after the installation is complete and permit has been closed out. A grid tied solar system without battery backup may be net -zero but does not provide the home with energy in the event of a power -outage, as the solar inverter will automatically shut down in the absence of power from the grid. This is known as "anti-islanding" and is in place to protect the lives of powerline workers (it prevents back -feed of current to a grid that is down and worked on). For the solar' system to function as a power source for backup in a power outage, backup batteries will be necessary. b. The net -meter installation by the local power utility will require an "Interconnection Agreement" between the Owner and the utility. The Interconnection Agreement will govern the terms of the net metering relationship between the Owner and utility. The particular details of the interconnection agreement will vary from utility to utility, and based on the size of the solar system in kW (Tier 1, Tier 2 or Tier 3) that is being interconnected. The interconnection agreement required by the utility may be accompanied by a one-time fee for the net meter and insurance requirements. Owner has reviewed and understands the interconnection agreement required by their local utility for their relevant solar system size. c. Solar Insolation is an inconsistent energy source which varies seasonally and with daily weather fluctuation. The power output of the solar array is also a function of the tilt and orientation (azimuth) of the solar installation. For maximum energy production, it is important to keep the solar panels free of shade cadsed by trees, buildings or other sources. Contractor is not responsible for tree trimming or any other shade prevention. For this reason, contractor does not guarantee system power output. However, contractor does provide estimated annual energy output in kWh based on Page 8 of 13 Owner initials: Contractor initials: GOLDIN SOLAR system power rating in kW. To understand the total annual kWh energy output for the system contracted herein, match the system power rating as outlined in Article 1; Item 1, with the annual energy output in kWh in the following table: Power Rating of System (kW) Expected Annual Energy Production (kWh) 5 7,592 7 10,629 10 15,184 12 18,221 15 22,776 20 30,368 25 37,960 The above table is based on 5.2 Peak Sun Hours per day, which is the average daily solar insulation for South Florida, and 80% conversion factor from DC to AC power. Monetary value of energy savings expressed as avoided cost of energy not purchased from utility will vary depending on retail price of energy from the local utility. Initial: d. The solar Federal Investment Tax Credit (ITC) grants a 30% credit against an individual's or business' federal Income tax liability. Eligibility for this tax credit will vary on a case -by -case basis. Goldin Solar does•not give tax advice and makes no guarantees as to your eligibility to this tax credit Initial under this paragraph to confirm that you have consulted with your accountant and understand your eligibility to the federal ITC. Initial: Page 9 of 13 Owner initials: Contractor initials: 17_ GOLDIN SOLAR ACCORDING TO FLORIDA'S CONSTRUCTION LIEN LAW (SECTIONS 713.001-713.37, FLORIDA STATUTES), THOSE WHO WORK ON YOUR PROPERTY OR PROVIDE MATERIALS AND SERVICES AND ARE NOT PAID IN FULL HAVE A RIGHT TO ENFORCE THEIR CLAIM FOR PAYMENT AGAINST YOUR PROPERTY. THIS CLAIM IS KNOWN AS A CONSTRUCTION LIEN. IF YOUR CONTRACTOR OR A SUBCONTRACTOR FAILS TO PAY SUBCONTRACTORS, SUB -SUBCONTRACTORS, OR MATERIAL SUPPLIERS, THOSE PEOPLE WHO ARE OWED MONEY MAY LOOK TO YOUR PROPERTY FOR PAYMENT, EVEN IF YOU HAVE ALREADY PAID YOUR CONTRACTOR IN FULL. IF YOU FAIL TO PAY YOUR CONTRACTOR, YOUR CONTRACTOR MAY ALSO HAVE'A LIEN ON YOUR PROPERTY. THIS MEANS IF A LIEN IS FILED YOUR PROPERTY COULD BE SOLD AGAINST YOUR WILL TO PAY FOR LABOR, MATERIALS, OR OTHER SERVICES THAT YOUR CONTRACTOR OR A SUBCONTRACTOR MAY HAVE FAILED TO PAY. TO PROTECT YOURSELF, YOU SHOULDJTIPULATE IN THIS ONTRACT THAT BEFORE ANY PAYMENT IS MADE, YOUR CONTRACTOR IS REQUIRED TO PROVIDE YOU WITH A WRITTEN RELEASE OF LIEN FROM ANY PERSON OR COMPANY THAT HAS PROVIDED TO YOU A ,! "NOTICE TO OWNER." FLORIDA'S CONSTRUCTION LIEN LAW IS COMPLEX, AND IT IS RECOMMENDED THAT YOU CONSULT A ATTORNEY. uyer's Signature Owner initials: Contractor initials: J2-t- Date Page 10 of 13 GOLDIN• SQLAR FLORIDA HOMEOWNERS' CONSTRUCTION RECOVERY FUND PAYMENT, UP TO A LIMITED AMOUNT, MAY BE AVAILABLE FROM THE FLORIDA HOMEOWNERS' CONSTRUCTION RECOVERY FUND IF YOU LOSE MONEY ON A PROJECT PERFORMED UNDER CONTRACT, WHERE THE LOSS RESULTS FROM SPECIFIED VIOLATIONS OF FLORIDA LAW BY A LICENSED CONTRACTOR. FOR INFORMATION ABOUT THE RECOVERY FUND AND FILING A CLAIM, CONTACT THE FLORIDA CONSTRUCTION INDUSTRY LICENSING BOARD AT THE FOLLOWING TELEPHONE NUMBER AND ADDRESS: Construction Industry Licensing Board 2601 Blairstone Road Tallahassee, FL 32399-1039 850-487-1395 t The Owner's property is governed by a Home Owner's Association Yes / No V If yes, the Home Owner's Association's Contact Information is Owner initials: Contractor initials: 6� Page 11 of 13 GOLDIN SOLAR Signatories Contractor: D6 r-� 60(a,h �- .. AY- 3 ► ti / 0 ►:� Print Name Signature Date Daren Goldin, Owner/Founder Goldin Solar, LLC (305) 469-9790 dgoldin@goldinsolar.com You, the buyer, may cancel this transaction at any time prior to midnight of the third business day after the date of this transaction. See the attached notice of cancellation form for an explanation of this right. Owner: 6 cl Actir Print Name )<,,me f � { c, .i t Print Name Address: Phone: Email: li -. zo/e. Signature Date Ignature Date 0?A J ci q S J- , ct pvt S It a,. e S F.1 r 3 cS 0,1r 7s- 2.S`7•-5.34.S" .Q-o t 3 o.S'- 3 [8 `t -- S l be. J7 o► 7% S 3 Co' Z c&-t iBCArb4rck e �7-1~+Cc��be.r-cam or..:J 'OI AyQr'e_k0, l i%V1cteI t CoYidl Page 12 of 13 Owner initials: Contractor initials: 1:7 (s GOLDIN SOLAR NOTICE OF RIGHT TO CANCEL — DATE: _ You may CANCEL this transaction, without any Penalty or Obligation, within THREE BUSINESS DAYS from the above date. If you cancel, any property traded in, any payments made by you under the contract or sale, and any negotiable instrument executed by you will be returned within TEN BUSINESS DAYS following receipt by the seller of your cancellation notice, and any security interest arising out of the transaction will be cancelled. If you cancel, you must make available to the seller at your residence, in substantially as good condition as when received, any goods delivered to you under this contract or sale, or you may if you wish, comply with the instructions of the seller regarding the return shipment of the goods at the seller's expense and risk. If you do make the goods available to the seller and the seller does not pick them up within 20 days of the date of your Notice of Cancellation, you may retain or dispose of the goods without any further obligation. If you fail to make the goods available to the seller, or if you agree to return the goods to the SELLER and fail to. do so, then you remain liable for performance of all obligations under the contract. To cancel this transaction, mail or deliver a signed and dated copy of this Cancellation Notice or any other written notice, or send a telegram to Goldin Solar 3447 Percival Ave Miami, FL 33133 Not Later than Midnight of: T-Mpe ddipsollar' 3 7/6/if I HEREBY CANCEL THIS TRANSACTION. Buyer's Signature Owner initials: Contractor initials: t Date Page 13 of 13 Miami Shores Village Building Department 10050 N.E.2nd Avenue Miami Shores, Florida 33138 Tel: (305) 795.2204 Fax: (305) 756.8972 Notice to Owner — Workers' Compensation Insurance Exemption Florida Law requires Workers' Compensation insurance coverage under Chapter 440 of the Florida Statutes. Fla. Stat. § 440.05 allows corporate officers in the construction industry to exempt themselves from this requirement for any construction project prior to obtaining a building permit.' Pursuant to the Florida Division of Workers' Compensation Employer Facts Brochure: An employer in the construction industry who employs one or more part-time or full-time employees, including the owner, must obtain workers' compensation coverage. Corporate officers or members of a limited liability company (LLC) in the construction industry may elect to be exempt if: 1. The officer owns at least 10 percent of the stock of the corporation, or in the case of an LLC, a statement attesting to the minimum 10 percent ownership; 2. The officer is listed as an officer of the corporation in the records of the Florida Department of State, Division of Corporations; and 3. The corporation is registered and listed as active with the Florida Department of State, Division of Corporations. No more than three corporate officers per corporation or limited liability company members are allowed to be exempt. Construction exemptions are valid for a period of two years or until a voluntary revocation is filed or the exemption is revoked by the Division. Your contractor is requesting a permit under this workers' compensation exemption and has acknowledge that he or she will not use day labor, part-time employees or subcontractors for your project. The contractor has provided an affidavit stating that he or she will be the only person allowed to work on your project. In these circumstances, Miami Shores Village does not require verification of workers' compensation insurance coverage from the contractor's company for day labor, part-time employees or subcontractors. BY SIGNING BELOW YOU ACKNOWLEDGE THAT YOU HAVE READ THIS NOTICE AND UNDERSTAND ITS CONTENTS. Signature: State of Florida County of Miami -Dade The foregoing was acknowledge before me this (03 day of Byeg,P Vavv9 Notary: SEAL: , 20 1 Y who is personally known to me or has produced as identification. 0,�r Notary Public State of Florida ° Madelin Rojas My Commission GG 157509 y+� -0•° Expires 11105/2021. Goldin Solar, LLC Certified Florida Solar Contractor, License number: CVC56965 Cell #: (305) 469 9790 dgoldin@goldinsolar.com www.goldinsolar.com GOLD OLAR 06/04/2018 State of F I (24►C'CI County of 0.(C( 1.(— DCde_ ``rjy� Before me this day personally appeared �"ota(C'..� o(d4 deposes and says: That he or she will be the only person working on the project located at: c16 � qq S± 'f ►om, Skc ie f=L 33i3$' g; 4 Contractor Signature A9- Swor to (or affirmed)yand subscribed before me this By L.(.tre A 0161`l who, being duly sworn day of \_unt , 20 I J Personally Known lam" Or Produced Identification Type of identification Print, type, or stamp name of notary ostAv ky Notary Public State of Florida `� Madelin Rojas c z My Commission GG 15750G "40iop* Expires 11/05/2021 Miami Shores Village Building Department 10050 N.E.2nd Avenue Miami Shores, Florida 33138 Tel: (305) 795.2204" Fax: (305) 756.8972 Notice to Owner — Workers' Compensation Insurance Exemption Florida Law requires Workers' Compensation insurance coverage under Chapter 440 of the Florida Statutes. Fla. Stat. § 440.05 allows corporate officers in the construction industry to exempt themselves from this requirement for any construction project prior to obtaining a building permit. Pursuant to the'Florida Division of Workers' Compensation Employer Facts Brochure: An employer in the construction industry who employs one or more part-time or full-time employees, including the owner, must obtain workers' compensation coverage. Corporate officers or members of a limited liability company (LLC) in the construction industry may elect to be exempt if: 1. The officer owns at least 10 percent of the stock of the corporation, or in the case of an LLC, a statement attesting to the minimum 10 percent ownership; 2. The officer is listed as an officer of the corporation in the records of the Florida Department of State, Division of Corporations; and 3. The corporationis registered and listed as active with the Florida Department of State, Division of Corporations. No more than three corporate officers per corporation or limited liability company members are allowed to be exempt. Construction exemptions are valid for a period of two years or until a voluntary revocation is filed or the exemption is revoked by the Division. Your contractor is requesting a permit under this workers' compensation exemption and has acknowledge that he or she will not use day labor, part-time employees or subcontractors for your project. The contractor has provided an affidavit stating that he or she will be the only person allowed to work on your project. In these circumstances, Miami Shores Village does not require verification of workers' compensation insurance coverage from the contractor's company for day labor, part-time employees or subcontractors. BY SIGNING BELOW YOU ACKNOWLEDGE THAT YOU HAVE READ THIS NOTICE AND UNDERSTAND ITS CONTENTS. Signature: State of Florida County of Miami -Dade The foregoing was acknowledge before me this By J PT Vamp LD (-y-2 a 0:4,, day of WaLi , 20 ( . who is personally known to me or has produced as identification. Notary:, SEAL: ��►+ �o.� Notary Public State of Florida Madelin Rojas y t My Commission GG 157509 140 Expires 11/05/2021 4 Goldin Solar, LLC Certified Florida Solar Contractor, License number: CVC56965 Cell #: (305) 469 9790 dgoldin@goldinsolar.coril www.goldinsolar.com GOASOLAR iff 06/04/2018 State of Lido County of 01Ci Y1l.-DG,tCie_ Before me this day personally appeared deposes and says: / \ i1W( LOT cc7 1 That he or she will be the only person working on the project located at: who, being duly sworn 416 Id: qq i h 1`i ctut' 1 Shoces,1: L S3 i 3' Contractor Signature Sworn to (or affirmed) and subscribed before me this day of unc. , 20 e By e.lLC7 Personally Known Or Produced Identification Type of identification Print, type, or stamp name of notary • f I Notary Public State of Florida Madelin Rojas My Commission GG 157509 Expires 11/05/2021 Miami Shores Village Building Department 10050 N.E.2nd Avenue Miami Shores, Florida 33138 Tel: (305) 795.2204 Fax: (305) 756.8972 Solar Installation Requirements Check type of Solar System to be installed: ❑ Solar Thermal Required Inspections: PLumbing Solar Final Electrical Solar Final Structural Solar Final Solar Electrical ❑ Solar Hybrid Required Inspections: Required Inspections: Electrical Solar Rough Electrical Solar Rough Electrical Solar Final Electrical Solar Final Structural Solar Final PLumbing Solar Final Structural Solar Final Owner Notification: Installation of roof mounted photovoltaic or solar support systems typically require roof system Penetrations to allow attachment to the structure which may create additional long-term roof system maintenance requirements and/or jeopardize roof system manufacturer's warranties. Roof mounted solar systems generally required removal and reinstallation of solar panels/arrays in order to perform routine roof system maintenance, repair or replacement. -01 I hereby acknowled a that I have read and understand the above notification on this o�? day of k ale - Print owner name bra alit J P a k cu p Owner signature Property address , 20 L 14.e‘412Cie-;*/ S-Free--i' Miami Shores, FL 3 '3 13 g Permit Notary stamp Print Notary Name 0Y r� Notary Public State of Florida ° c: Madelin Rojas My Commission GG 157509 +).# of tv/ Expires 11 /05/2021 ,Alreed